47 -- HOSE

Notice Date

March 14, 2001

Contracting Office

Regional Contracting Department (Code 201), Fleet and Industrial Supply Center, 1942 Gaffney Street, Ste 100, Pearl Harbor, HI 96860-4549

ZIP Code

96860-4549

Solicitation Number

N00604-01-T-A528

Response Due

March 23, 2001

Point of Contact

Wanda Okemura, Contract Specialist, (808)473-7543

Description

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being required and a written solicitation will not be issued. The provisions and clauses in the RFQ are those in effect through FAC 97-21 and DAC 91-13. This requirement is unrestricted. The Regional Contracting Department, Pearl Harbor, Hawaii intends to negotiating a single contract for the following items: 0001 -- Hose, Flexible, 4" ID X 25 Feet long, spring steel helix wire of .105" diameter or 12 gauge min. with 1 1/4" pitch 2 ply polyester base fabric coated laminated with a flame retardant compound (to meet UL-94-VO Test method), coated fabric to weigh a minimum of 12 oz per square yard, hose to have external scuff strip over the helix (scuff strip to meet high abrasion resistance per federal test method std. no. 191A method 5304 (FED-STD-191A, Method 5304) -20 degree F to 180 degree F, intermittent to 225 degree F, hose to be black with black wear strip, stainless steel nameplate to be affixed to hose to include: 1) manufacture name, 2) date of manufacture, 3) purchase order number, Dura-Vent p/n: 2PVBK-BW or equal, Qty 100 each; Item 0002 -- Hose, Flexible, 6" ID X 25 Feet long, spring steel helix wire of .105" diameter or 10 gauge min. at 1.250" pitch, 2 ply polyester PVC scrim cloth min. weight of 12 oz per square yard, cloth to meet flame retardant method UL-94-VO, hose to have external scuff strip over the helix wire (scuff strip to meet high abrasion resistance standard No. 191A, method 5304), hose rated -20 degree F to 180 degree F, intermittent to 225 degree F, hose to be black with black wear strip, stainless steel nameplate to be affixed to hose to include: 1) manufacture name, 2) date of manufacture, 3) purchase order number, Dura-Vent p/n: 2PVBK-BW or equal, Qty 100 each;; Item 0003 -- Hose, Flexible, 8" ID X 25 Feet long, spring steel helix wire of .135" diameter or 10 gauge min. at 1" pitch, 2 ply PVC scrim cloth min. weight of 12 oz per square yard, cloth to meet flame retardant method UL-94-VO, hose to have external scuff strip over the helix wire (scuff strip to meet high abrasion resistance test method std. no. 191A method 5304), hose rated -20 degree F to 180 degree F, intermittent to 225 degree F, hose to be black with black wear strip, stainless steel nameplate to be affixed to hose to include: 1) manufacture name, 2) date of manufacture, 3) purchase order number, Dura-Vent p/n: 2PVBK-BW or equal, Qty 50 each;, Delivery of all items FOB Destination to Pearl Harbor NSY & IMF, 677 Safeguard Street, Bldg. 167, Pearl Harbor, HI 96860-5033. POC: Code 512, (808)471-1133. The FSC Code is 4720. NAICS code and the small business size standard for this procurement is 335999 and 500 respectively. All contractors must be registered in the Central Contracting Registration database to be eligible for Department of Defense contract awards. All qualified responsible business sources may submit a quotation, which shall be considered by the agency. Quoters are encouraged to use the Standard Form 1449, Solicitation/Contract/Order for Commercial Items form found at http://www.gsa.gov/forms/pdf_files/sf1449.pdf to submit a quotation. Quoters shall provide the following information required by FAR 52.212-3, Offeror Representations and Certification -- Commercial Items. The following clauses apply: FAR 52.211-6, Brand Name or Equal; FAR 52.212-1, Instructions to Offerors -- Commercial; FAR 52.212-2, Evaluation -- Commercial Items -- the following factors shall be used to evaluate offers: (1) Technically Acceptable and (2) Price. The Government intends to award a single contract resulting from this solicitation. FAR 52.212-4, Contract Terms and Conditions -- Commercial Items, and FAR 52.212-5, Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items. Under this clause, the following are incorporated by reference: FAR 52.222-21 -- Prohibition of Segregated Facilities, FAR 52.222-26 -- Equal Opportunity (E.O 11246), FAR 52.222-35 -- Affirmative Action for Disabled Veterans and Veterans of the Vietnam Era (38 U.S.C. 4212), FAR 52.222-36 -- Affirmative Action for Workers with Disabilities (29 U.S.C. 793), FAR 52.222-37 -- Employment Reports on Disabled Veterans and Veterans of the Vietnam Era (38 U.S.C. 4212), FAR 52.232-33 -- Payment by Electronic Funds Transfer -- Central Contractor Registration (31 U.S.C. 3332),; FAR 52.219-1 Alt I -- Small Business Program Representations; DFARS 252.204-7004 -- Required Central Contractor Registration; and DFARS 252.212-7001 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders Applicable to Defense Acquisitions of Commercial Items. Under this clause, the following is incorporated by reference: DFARS 252.225-7001, Buy American Act and Balance of Payments Program (41 U.S.C. 10a-10d, E.O. 10582). These clauses may be obtained via the Internet at http://www.arnet.gov/far; http://farsite.hill.af and http://www.acq.osd.mil/dp/dars/html. REVIEW OF AGENCY PROTESTS (FISCPH) (APR 2000) (a) The contracting activity, Fleet and Industrial Supply Center, Pearl Harbor (FISCPH), will process agency protests in accordance with the requirements set forth in FAR 33.103(d). (b) Pursuant to FAR 33.103(d)(4), agency protests may be filed directly with the appropriate Reviewing Authority or a protester may appeal a decision rendered by a Contracting Officer to the Reviewing Authority. (c) The Reviewing Authority for FISCPH is the Deputy Director, Regional Contracting Department (Code 200A), Fleet and Industrial Supply Center, Pearl Harbor, at 1942 Gaffney Street, Suite 100, Pearl Harbor, HI 96860-4549. Agency procurement protests should clearly identify the initial adjudicating official, i.e., the "Contracting Officer" or "Reviewing Official". (d) Offerors should note this review of the Contracting Officer's decision will not extend GAO's timeliness requirements. Therefore, any subsequent protest to GAO must be filed within 10 days of knowledge of initial adverse agency action. Proposals must be received no later than 3:30pm, HST, 23 March 2001. Proposals should be e-mailed to wanda_l_okemura@pearl.fisc.navy.mil, Attn: Wanda L. Okemura, mailed to Regional Contract Department, Fleet and Industrial Supply Center, Code 210A.WO, Bldg 475, 2nd Deck, 1942 Gaffney Street, Ste 100, Pearl Harbor, HI 96860-4549, or faxed to (808)473-0811 or 473-2008.

Record

Loren Data Corp. 20010316/47SOL002.HTM (W-073 SN50G299)