|
COMMERCE BUSINESS DAILY ISSUE OF AUGUST 1,1997 PSA#1900U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO.
1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH
STREET MOBILE AL 36602 Y -- MISSILE AND SPACE INTELLIGENCE CENTER REDSTONE ARSENAL, AL SOL
DACA01-97-R-0092 DUE 093097 POC Contact Karen Johnson, (334) 690-2535;
Contracting Officer, Edward M. Slana (Site Code W31XNJ) Construct a
4-story administration building with basement, 400 seat auditorium,
life support activity center, high bay/medium bay laboratory space, and
stand alone central energy plant. Also, parking support roads,
hardstands and applicable utilities. The total roof covered foot print
of the complex is in excess of 200,000 sq ft. Bidders, subcontractors
and Dodge/Plan Rooms are encouraged to register on the Internet to
receive one CD-ROM. Registration on the Internet should minimize
possible errors and delay in receiving the CD-ROM. Registration
instructions are available on the Internet at
http://www.sam.usace.army.mil/sam/ct. Registration may also be
completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic
requests will not be accepted. In either case, those registering are
responsible for the accuracy of the information on the mailing list.
Registration must include the firms physical address, telephone, fax
number and a point of contact. Registration should be completed one
week prior to the issue date. All notifications of changes to this
solicitation shall be made through the Internet only. It is therefore
the contractors responsibility to check the Internet address listed
above daily, for any posted changes to this solicitation. Actual
solicitation amendments will be issued either by fax 3.5" diskette or
CD- ROM. The plans and specifications will be issued on Compact Disc
(CD-ROM) only and will be provided free of charge. Plans and
specifications will not be provided in a printed paper format; however,
the Government reserves the right to revert to paper medium when it is
determined to be in the Government's best interest. All bid forms, bid
bonds, and other normal documents required for the bid submittal,
including amendments to the bid submittal, shall be in paper medium.
Electronic medium for the bid submittal documents will not be allowed.
Critical path method (Network Analysis System) is required. For this
job, a small business is defined as having average annual receipts of
lessthan $17,000,000 for the past three years. This solicitation
includes bid options which may not be awarded. Specific questions
related to this project may be answered by George Poiroux at
334-694-4082, fax 334-690-2902. Refer questions on distribution of
plans/specifications to Plans Room at 334-690-2535. Bid documents are
available on or about 28 August 1997. Estimated cost of work is over
$10,000,000. Request for plans and specifications shall indicate in
writing whether firm will bid as a prime contractor or a subcontractor.
All responsible sources may submit an offer which shall be considered.
(0211) Loren Data Corp. http://www.ld.com (SYN# 0137 19970801\Y-0023.SOL)
Y - Construction of Structures and Facilities Index Page
|
|