U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

C -- EMCS CONNECTIONS, FT RUCKER, ALABAMA SOL DACA01-97-B-0099 DUE 090997 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Gene L. Curtis (Site Code W31XNJ) Connection of various buildings to existing energy monitoring and control system. Bid documents are available on or about 8 August 1997. Cost for plans and specifications for this job are free of charge. Estimated cost of work is between $250,000 to $500,000. Requests for plans and specifications shall indicate in writing whether firm will bid as a prime contractor a subcontractor. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instructions are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic requests will not accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to the issue date. All notification of changes to this solicitation shall be made through the Internet only. It is therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. For this job, a small business is defined as having average annual receipts of less than than $17,000,000 for the past three years. This solicitation included bid options which may not be awarded.Critical Path Method (Network Analysis System) is not required. Specific questions related to this project may be answered by Shirley Hooker at 334-694-3791, fax 334-690-2700. Refer questions on distribution of plans/specifications to PlansRoom at 334-690- 2535. Unrestricted. All responsible sources may submit a bid which shall (0204)

Loren Data Corp. http://www.ld.com (SYN# 0017 19970728\C-0001.SOL)