SOLICITATION NOTICE
J -- Awning Replacement for NOAA Ship Sette in Honolulu, HI - Statement of Work
- Notice Date
- 9/9/2019
- Notice Type
- Combined Synopsis/Solicitation
- NAICS
- 336611
— Ship Building and Repairing
- Contracting Office
- Department of Commerce, National Oceanic and Atmospheric Administration (NOAA), Office of Marine and Aviation Operations, SSMC3 - Room 10350/NMAO2, 1315 East West Highway, 10th Floor, Silver Spring, Maryland, 20910, United States
- ZIP Code
- 20910
- Solicitation Number
- NMAN7937-19-01548
- Archive Date
- 10/1/2019
- Point of Contact
- Joel Heisler, Phone: 541-867-8763
- E-Mail Address
-
Joel.Heisler@noaa.gov
(Joel.Heisler@noaa.gov)
- Small Business Set-Aside
- Total Small Business
- Description
- Statement of Work Combined Synopsis/Solicitation (Best Value) The National Oceanic and Atmospheric Administration (NOAA), Office of Marine and Aviation Operations/Marine Operations Center - Pacific requires extension of the fly bridge awning and replacement of the wing bridge awnings on the NOAA ship Oscar Sette. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. (ii) Solicitation number NMAN7937-19-01548 is issued as a firm fixed price, commercial, request for quotation (RFQ). (iii) The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2019-05. (iv) The NAICS code for this acquisition is 336611, Ship Repair; the small business size standard is 1250 employees. This is a small business set aside. (v) Line items are as follows: CLIN 1: Extension of the fly bridge awning and replacement of the wing bridge awnings. (vi) Description of requirements for the items to be acquired: The NOAA ship Oscar Sette requires extension on the fly bridge awning and replacement of the wing bridge awning in accordance with the attached statement of work. Please provide •Pricing for extension of the fly bridge awning •Pricing for replacement of the wing bridge awnings using steel •Additional costs for the wing bridge awnings if using aluminum The ship currently has specific funds set aside for this requirement, and will be seeking to use aluminum instead of steel if pricing is acceptable. Otherwise, steel will be the correct choice. Please also note the ship repair clauses, including insurance requirements, as well as ABS coordination at the time of install. (vii) Date(s) and place(s) of delivery and acceptance. NOAA Ship Oscar Sette 1897 Ranger Loop, Ford Island, JBPHH, Honolulu, HI 96818. (viii) The provision at 52.212-1, Instructions to Offerors-Commercial, applies to this acquisition without addenda. (ix) The provision at 52.212-2, Evaluation-Commercial Items, applies to this acquisition. The specific evaluation criteria per in paragraph (a) of that provision is below: (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: •Demonstrated capacity to meet the requirements as shown in the Statement of Work. •Price •Past Performance •Factors are listed in order of importance. This will be awarded based on best value for the government. Evaluation Criteria Ratings and Definitions: Technical - "Exceeds" - Offer provides accelerated completion schedule (at a reasonable price), proposes specific cost savings, or other such benefit to the Government. "Meets" - Satisfies the requirement but does not offer added benefit. "Does Not Meet" - Offer does not adequately demonstrate understanding; i.e. offer only addresses pricing and not approach. Past Performance - "Acceptable" - Has satisfactory or better past performance either with NOAA or as documented in the Past Performance Information Retrieval System (PPIRS). "Not Acceptable" - Has negative past performance with NOAA or as documented in PPIRS. "No Past Performance" - Vendor has no past performance with NOAA or documented in PPIRS. This is a neutral rating and will not negatively affect ranking. Price - Offered prices for specific tasks performed or specific outcomes to be achieved and under standard commercial terms and conditions. (b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. (End of provision) (x) Offerors shall include a completed copy of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items. The Offeror shall complete only paragraph (b) of the provision at FAR 52.212-3 if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of the provision. (xi) 52.212-4 Contract Terms and Conditions -- Commercial Items (Oct 2018) (Deviation 2017-02) (Aug 2017) (a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights -- (1) Within a reasonable time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C. chapter 71,Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. ](e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include -- (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only ifrequired elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer- System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment. (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall- (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the- (A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected line item or subline item, if applicable; and (D) Contractor point of contact. (ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer. (6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract. (iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if- (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days; (B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or (C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates: (A) The date fixed under this contract. (B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on- (A) The date on which the designated office receives payment from the Contractor; (B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or (C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor. (vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or (2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination. (k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) (DEVIATION) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) The schedule of supplies/services. (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause. (3) The clause at 52.212-5. (4) Addenda to this solicitation or contract, including any license agreements for computer software. (5) Solicitation provisions if this is a solicitation. (6) Other paragraphs of this clause. (7) The Standard Form 1449. (8) Other documents, exhibits, and attachments. (9) The specification. (t) System for Award Management (SAM). (1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (2) (i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to: (A) Change the name in the SAM database; (B) Comply with the requirements of Subpart 42.12 of the FAR; (C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract. (3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov. (u) Unauthorized Obligations. (1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (i) Any such clause is unenforceable against the Government. (ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an "I agree" click box or other comparable mechanism (e.g., "click-wrap" or "browse-wrap" agreements), execution does not bind the Government or any Government authorized end user to such clause. (iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. (v) Incorporation by reference. The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract. (End of Clause) (xii) The clause at 52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Jan 2019) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91). (3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (4) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (5) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). ___ (4) 52.203-17, Contractor Employee Whistleblower Rights and Requirement to Inform Employee of Whistleblower Rights (Oct 2018) ____(5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (6) [Reserved] ___ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (9) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note). ___ (10) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313). ___ (11) [Reserved] ___ (12) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (ii) Alternate I (Nov 2011) of 52.219-3. ___ (13) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (ii) Alternate I (Jan 2011) of 52.219-4. ___ (14) [Reserved] _X_ (15) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (16) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. ___ (17) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)). ___ (18) (i) 52.219-9, Small Business Subcontracting Plan (Aug 2018) (15 U.S.C. 637 (d)(4)). ___ (ii) Alternate I (Nov 2016) of 52.219-9. ___ (iii) Alternate II (Nov 2016) of 52.219-9. ___ (iv) Alternate III (Nov 2016) of 52.219-9. ___ (v) Alternate IV (Aug 2018) of 52.219-9. _X_ (19) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). ___ (20) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). ___ (21) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (22) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). _X__ (23) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). ___ (24) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). ___ (25) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). _X_ (26) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (27) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126). _X_ (28) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X_ (29) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). ___ (ii) Alternate I (Feb 1999) of 52.222-26. ___ (30) (i) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). ___ (ii) Alternate I (July 2014) of 52.222-35. _X_ (31) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). ___ (ii) Alternate I (July 2014) of 52.222-36. ___ (32) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). ___ (33) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X_ (34) (i) 52.222-50, Combating Trafficking in Persons (JAN 2019) (22 U.S.C. chapter 78 and E.O. 13627). ___ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627). ___ (35) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (36) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (37) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693). ___ (38) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). ___ (39) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514 ___ (ii) Alternate I (Oct 2015) of 52.223-13. ___ (40) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-14. ___ (41) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (42) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). ___ (ii) Alternate I (Jun 2014) of 52.223-16. _X_ (43) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513). ___ (44) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). ___ (45) 52.223-21, Foams (Jun 2016) (E.O. 13696). ___ (46) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). ___ (ii) Alternate I (Jan 2017) of 52.224-3. _X_ (47) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83). ___ (48) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). ___ (ii) Alternate I (May 2014) of 52.225-3. ___ (iii) Alternate II (May 2014) of 52.225-3. ___ (iv) Alternate III (May 2014) of 52.225-3. ___ (49) 52.225-5, Trade Agreements (Aug 2018) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X_ (50) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (51) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). ___ (52) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (53) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (54) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)). ___ (55) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _X_ (56) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Oct 2018) (31 U.S.C. 3332). ___ (57) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (58) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). ___ (59) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (60) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)). ___ (61) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. ___ (iii) Alternate II (Feb 2006) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) ___ (2) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67.). ___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C.206 and 41 U.S.C. chapter 67). ___ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). ___ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67). _X_ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67). ___ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). ___ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). ___ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Jan 2019) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91). (iv) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (v) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (vii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (viii) 52.222-35, Equal Opportunity for Veterans (Oct 2019) (38 U.S.C. 4212). (ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (x) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). (xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xii) 52.222-41, Service Contract Labor Standards (Aug 2018), (41 U.S.C. chapter 67). (xiii) (A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter 78 and E.O. 13627). (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627). (xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.) (xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67) (xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989). (xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xviii) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (xix) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (B) Alternate I (Jan 2017) of 52.224-3. (xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xxii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) (xiii) Additional Federal Acquisition Regulation terms and conditions apply to this acquisition: 52.252-1 Solicitation Provisions Incorporated by Reference. (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov/?q=browsefar (xiv) The following Federal Acquisition Regulation terms and conditions apply to this acquisition and are included by reference: 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction Under Any Federal Law (FEB 2016) 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013) 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation (JAN 2017) 52.204-7 System for Award Management (OCT 2016) 52.204-13, System for Award Management Maintenance (Oct 2018) 52.252-5 Authorized Deviations in Provisions (APR 1984) (a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision. (b) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision. (End of provision) 52.252-6 Authorized Deviations in Clauses (Apr 1984) (a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause. (b) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation. (End of clause) (xv) The following Department of Commerce and National Oceanic and Atmospheric terms and conditions apply to this acquisition: 1352.201-70, Contracting Officer's Authority (APR 2010) The Contracting Officer is the only person authorized to make or approve any changes in any of the requirements of this contract, and, notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely in the Contracting Officer. In the event the contractor makes any changes at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract terms and conditions, including price. (End of clause) 1352.209-73, Compliance with the Laws (APR 2010) The contractor shall comply with all applicable laws, rules and regulations which deal with or relate to performance in accord with the terms of the contract. (End of clause) 1352.209-74, Organizational Conflict of Interest (APR 2010) (a) Purpose. The purpose of this clause is to ensure that the contractor and its subcontractors: (1) Are not biased because of their financial, contractual, organizational, or other interests which relate to the work under this contract, and (2) Do not obtain any unfair competitive advantage over other parties by virtue of their performance of this contract. (b) Scope. The restrictions described herein shall apply to performance or participation by the contractor, its parents, affiliates, divisions and subsidiaries, and successors in interest (hereinafter collectively referred to as "contractor") in the activities covered by this clause as a prime contractor, subcontractor, co-sponsor, joint venture, consultant, or in any similar capacity. For the purpose of this clause, affiliation occurs when a business concern is controlled by or has the power to control another or when a third party has the power to control both. (c) Warrant and Disclosure. The warrant and disclosure requirements of this paragraph apply with full force to both the contractor and all subcontractors. The contractor warrants that, to the best of the contractor's knowledge and belief, there are no relevant facts or circumstances which would give rise to an organizational conflict of interest, as defined in FAR Subpart 9.5, and that the contractor has disclosed all relevant information regarding any actual or potential conflict. The contractor agrees it shall make an immediate and full disclosure, in writing, to the Contracting Officer of any potential or actual organizational conflict of interest or the existence of any facts that may cause a reasonably prudent person to question the contractor's impartiality because of the appearance or existence of bias or an unfair competitive advantage. Such disclosure shall include a description of the actions the contractor has taken or proposes to take in order to avoid, neutralize, or mitigate any resulting conflict of interest. (d) Remedies. The Contracting Officer may terminate this contract for convenience, in whole or in part, if the Contracting Officer deems such termination necessary to avoid, neutralize or mitigate an actual or apparent organizational conflict of interest. If the contractor fails to disclose facts pertaining to the existence of a potential or actual organizational conflict of interest or misrepresents relevant information to the Contracting Officer, the Government may terminate the contract for default, suspend or debar the contractor from Government contracting, or pursue such other remedies as may be permitted by law or this contract. (e) Subcontracts. The contractor shall include a clause substantially similar to this clause, including paragraphs (f) and (g), in any subcontract or consultant agreement at any tier expected to exceed the simplified acquisition threshold. The terms "contract," "contractor," and "Contracting Officer" shall be appropriately modified to preserve the Government's rights. (f) Prime Contractor Responsibilities. The contractor shall obtain from its subcontractors or consultants the disclosure required in FAR Part 9.507-1, and shall determine in writing whether the interests disclosed present an actual, or significant potential for, an organizational conflict of interest. The contractor shall identify and avoid, neutralize, or mitigate any subcontractor organizational conflict prior to award of the contract to the satisfaction of the Contracting Officer. If the subcontractor's organizational conflict cannot be avoided, neutralized, or mitigated, the contractor must obtain the written approval of the Contracting Officer prior to entering into the subcontract. If the contractor becomes aware of a subcontractor's potential or actual organizational conflict of interest after contract award, the contractor agrees that the Contractor may be required to eliminate the subcontractor from its team, at the contractor's own risk. (g) Waiver. The parties recognize that this clause has potential effects which will survive the performance of this contract and that it is impossible to foresee each circumstance to which it might be applied in the future. Accordingly, the contractor may at any time seek a waiver from the Head of the Contracting Activity by submitting such waiver request to the Contracting Officer, including a full written description of the requested waiver and the reasons in support thereof. (End of clause) 1352.215-72 Inquiries. Offerors must submit all questions concerning this solicitation in writing to joel.heisler@noaa.gov. Questions should be received no later than one (3) calendar day after the issuance date of this solicitation. Any responses to questions will be made in writing, without identification of the questioner, and will be included in an amendment to the solicitation. Even if provided in other form, only the question responses included in the amendment to the solicitation will govern performance of the contract. (End of clause) 352.233-70 Agency protests (APR 2010) (a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999). (b) Agency protests filed with the Contracting Officer shall be sent to the following address: Marine Operations Attn: Joel Heisler, Contracting Officer 2002 SE Marine Science Drive Newport, Oregon 97365 Email: joel.heisler@noaa.gov (c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: Barry Berkowitz Senior Procurement Executive and Director, Office of Acquisition Management U.S. Department of Commerce Room 6422 Herbert C. Hoover Building 14th Street and Constitution Avenue, N.W. Washington DC 20230 Fax: (202) 482-1711 (d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority. (e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue, NW. Washington DC 20230. Fax: (202) 482-5858. (End of clause) 1352.233-71 GAO and Court of Federal Claims protests (APR 2010) (a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed. (b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims. (c) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel, Chief, Contract Law Division Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue, NW. Washington DC 20230 Fax: (202) 482-5858. (End of clause) NATIONAL OCEANIC AND ATMOSPHERIC ADMINISTRATION (NOAA) ACQUISITION REGULATION CLAUSES 1330-52.237-70, Contractor Communications (a) A contractor employee shall be identified both by the individual's name and the contractor's name when: 1. Included in NOAA's locator, and 2. When submitting any type of electronic correspondence to any NOAA employee or stakeholder. (b) Any written correspondence from a contractor or any contractor employee shall be printed on company/organization letterhead or otherwise clearly identify the sender as an employee of the company or organization and shall identify the contract number. (c) Contractors and/or contractor employees shall clearly identify themselves as such in any verbal communications, whether in informal discussion or a formal meeting. (End of clause) 1330-52.222-70 NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy (MAY 2018) In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA. (a)Definitions. Contractor Employees - The term "contractor employees," as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members. Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim. Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true: •Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment; •Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual; •The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment. The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient's sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures. (b)Requirements. 1.It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment. 2.The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor. 3.If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the Contracting Officer's Representative (COR), subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6,.07, Reporting from Remote Locations. i.Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants' needs are addressed. ii.The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor's written policy (where applicable). 4. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within business days [30 unless a different number is inserted] of contract award or the date a contractor employee is assigned to perform under the contract, as applicable. Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion. Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance. i.The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA's Workplace Violence Program Manager. A link to the website including the required elements of the training is provided at: http://www.ago.noaa.gov/quicklinks/harassment_training.html. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed. ii.The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training. iii.NOAA's Workplace Violence Program Manager, COR, or CO may periodically review the contractor's training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor. iv.Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106. 5. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees. (c)Sexual Assault/Sexual Harassment (SASH) Helpline. For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee. All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including: •Phone: 1-866-288-6558 •Website & Online Chat: http://NOAASASHHelpline.org •Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores) •Text: (202) 335-0265 (d)Confidentiality. Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. "Confidentiality" means that the information shall only be shared with others who have a need to know the information to conduct their official duties. (e)Remedies. In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in: 1.Requiring the Contractor to remove a contractor employee or employees from the performance of the contract; 2.Requiring the Contractor to terminate a subcontract; 3.Suspension of contract payments until the Contractor has taken appropriate remedial action; 4.Termination of the contract for default or cause, in accordance with the termination clause of this contract; 5.Suspension or debarment; or 6.Other appropriate action. (End of Solicitation and Contract language) 1330-52.237-71 Government-Contractor Relations - Non-Personal Services Contract (SEPT 2017) (a)The Government and the Contractor understand and agree that the services to be delivered under this contract by the Contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the Contractor's personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations. (b)Contractor personnel under this contract shall not: (1)Be placed in a position where they are under relatively continuous supervision and control of a Government employee. (2)Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other Contractors performing under other NOAA contracts. (c)The services to be performed under this contract do not require the Contractor or the Contractor's personnel to exercise personal judgement and discretion on behalf of the Government. Rather, the Contractor's personnel will act and exercise personal judgement and discretion on behalf of the Contractor. (d)Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract. (e)Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies: (1)The Contractor shall notify the Contracting Officer in writing within 5 business days from the date of any situation or occurrence where the Contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or Contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance. (2)The Contracting Officer will review the information provided by the Contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the Contractor. The Contracting Officer's response will provide a decision on whether the Contracting Officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the is(End of Solicitation and Contract Language) 1330-52.237-72 Contractor Access to NOAA Facilities (a) 1.NOAA may close and or otherwise deny contractor employees access to a NOAA facility for a portion of a business day or longer for various reasons including, but not limited, to the following events: 2.The performance of this contract requires employees of the prime contractor or its subcontractors, affiliates, consultants, or team members ("contractor employees") to have access to and to the extent authorized, mobility within, a NOAA facility. i.Federal public holidays for Federal employees in accordance with 5 U.S.C. 6103; ii.Fires, floods, earthquakes, and unusually severe weather, including but not limited to snow storms, tornadoes, and hurricanes; iii.Occupational safety or health hazards; iv.Lapse in Appropriations; or v.Federal Statute, Executive Order, Presidential Proclamation, or any other unforeseen reason. 3. In such events, the contractor employees may be denied access to a NOAA facility that is ordinarily available for the contractor to perform work or make delivery, as required by the contract. 1330-52.270-304 NOAA Acquisition and Grants Office Ombudsman (Oct 2016) NAM a.The NOAA Acquisition and Grants Office (AGO) Ombudsman is available to organizations to promote responsible and meaningful exchanges of information. Generally, the purpose of these exchanges will be to: 1.Allow contractors to better prepare for and propose on business opportunities. 2.Advise as to technologies and solutions within the marketplace that the Government may not be aware of, or is not fully benefiting from. 3.Identify constraints in transparency and process. b.The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her. Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA. c.Before consulting with the AGO Ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations with the respective contracting officer for resolution. However, direct access to the AGO Ombudsman may be sought when an interested party questions the objectivity or equity of a contracting officer's decision, or when there is a bona fide reason to believe that reasonable, responsible, and objective consideration will not be received from an assigned contracting officer. d.There are several constraints to the scope of the AGO Ombudsman's authority, for instance: 1.Consulting with the AGO Ombudsman does not alter or postpone the timelines of any formal process (e.g., protests, claims, debriefings, employee employer actions, activities involving A-76 competition performance decisions, judicial or congressional hearings, or proposal, amendment, modification or deliverable due dates, etc.). 2.The AGO Ombudsman cannot participate in the evaluation of proposals, source selection processes, or the adjudication of protests or formal contract disputes. 3.The AGO Ombudsman is not authorized to generate or alter laws, judicial decisions, rules, policies, or formal guidance 4.The AGO Ombudsman is not authorized to develop or alter opportunity announcements, solicitations, contracts, or their terms or conditions. 5.The AGO Ombudsman cannot overrule the authorized decisions or determinations of the contracting officer. 6.The AGO Ombudsman has no authority to render a decision that binds AGO, NOAA, the Department of Commerce, or the U.S. Government. 7.The AGO Ombudsman is not NOAA's agent relative to the service of magistrate or judicial process and cannot be used to extend service of process to another party (whether federal, public, or a private entity). e.After review and analysis of a filed concern or recommendation, the AGO Ombudsman may refer the interested party to another more suitable federal official for consideration. Moreover, concerns, disagreements, and/or recommendations that cannot be resolved by the AGO Ombudsman will need to be pursued through more formal venues. f.The AGO Ombudsman is not to be contacted to request copies of forms and/or documents under the purview of a contracting officer. Such documents include Requests for Information, solicitations, amendments, contracts, modifications, or conference materials. g.Questions regarding this solicitation and contract language shall be directed to Rafael Roman, NOAA AGO Ombudsman, at Rafael.Roman@noaa.gov. 1352.271-70 Inspection and Manner of Doing Work (APR 2010) (a) All work and material shall be subject to the approval of the Contracting Officer or duly authorized representative. Work shall be performed in accordance with the plans and specifications of this contract as modified by any contract modification. (b) Unless otherwise specifically provided for in the contract, all operational practices of the contractor and all workmanship and material, equipment and articles used in the performance of work shall be in accordance with American Bureau of Shipping "Rules for Building and Classing Steel Vessels", U.S. Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F), U.S. Coast Guard Electrical Engineering Regulations (46 CFR Subchapter J), and U.S. Public Health Service "Handbook on Sanitation of Vessel Construction", in effect at the time of the contract award; and the best commercial maritime practices, except where military specifications are specified, in which case such standards of material and workmanship shall be followed. (c) All material and workmanship shall be subject to inspection and test at all times during the contractor's performance of the work to determine their quality and suitability for the purpose intended and compliance with the contract. In case any material or workmanship furnished by the contractor is found to be defective prior to redelivery of the vessel, or not in accordance with the requirements of the contract, the Government shall have the right prior to redelivery of the vessel to reject such material or workmanship, and to require its correction or replacement by the contractor at the contractor's cost and expense. This Government right is in addition to its rights under any Guarantee clause in this contract. If the contractor fails to proceed promptly with the replacement or correction of such material or workmanship, as required by the Contracting Officer, the Government may, by contract or otherwise, replace or correct such material or workmanship and charge to the contractor the excess cost to the Government. The contractor shall provide and maintain an inspection system acceptable to the Government covering the work specified in the contract. Records of all inspection work by the contractor shall be kept complete and available to the Government during the performance of the contract and for a period of two (2) years after delivery of the vessel to the Government. (d) No welding, including tack welding and brazing, shall be permitted in connection with repairs, completions, alterations, or addition to hulls, machinery or components of vessels unless the welder is, at the time, qualified to the standards established by the U.S. Coast Guard, the American Bureau of Shipping, or the Department of the Navy. The welder's qualifications shall be appropriate for the particular service application, filler material type, position of welding, and welding process involved in the work being undertaken. A welder may be required to re-qualify if the Contracting Officer believes there is a reasonable doubt concerning the welder's ability. Welders' qualifications for this purpose shall be governed by the U.S. Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F). When a welding process other than manual shielded arc is proposed or required, the contractor or fabricator shall submit procedure qualification tests for approval prior to production welding. Procedure qualification tests shall be conducted in accordance with the United States Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F). (e) The contractor shall exercise reasonable care to protect the vessel from fire, and the contractor shall maintain a reasonable system of inspection over the activities of welders, burners, riveters, painters, plumbers and similar workers, particularly where such activities are undertaken in the vicinity of the vessel's fuel oil tanks, magazines or storerooms containing flammable material. A reasonable number of hose lines shall be maintained by the contractor ready for immediate use on the vessel at all times while the vessel is berthed alongside the contractor's pier or in dry dock or on a marine railway. All tanks or bilge areas under alteration or repair shall be cleaned, washed, and steamed out or otherwise made safe by the contractor if and to the extent necessary as required by good marine practice or by current Occupational Safety and Health Administration regulations. The Contracting Officer's Representative (COR) shall be furnished with a "gas free" or "safe for hot work" or "safe for workers" certificate before any hot work or entry is done. Unless otherwise provided in this contract, the contractor shall at all times maintain a reasonable fire watch about the vessel, including a fire watch on the vessel while work is being performed thereon. (f) The contractor shall place proper safeguards and/or effect such safety precautions as necessary, including suitable and sufficient lighting, for the prevention of accidents or injury to persons or property during the prosecution of work under this contract and/or from time of receipt of the vessel until acceptance by the Government of the work performed. (g) Except as otherwise provided in this contract, when the vessel is in the custody of the contractor or in dry dock or on a marine railway and the temperature becomes as low as 35 degrees Fahrenheit, the contractor shall keep all pipelines, fixtures, traps, tanks, and other receptacles on the vessel drained to avoid damage from freezing, or if this is not practicable, the vessel shall be kept heated to prevent such damage. The vessel's stern tube and propeller hubs shall be protected from frost damage by applied heat through the use of a salamander or other proper means, as approved by the COR. (h) Whenever practicable, the work shall be performed in a manner which does not interfere with the berthing and messing of personnel attached to the vessel. The contractor shall ensure that assigned personnel have access to the vessel at all times. It is understood that such personnel will not interfere with the work or the contractor's workers. (i) The Government does not guarantee the correctness of the dimensions, sizes, and shapes shown in any sketches, drawings, plans or specifications prepared or furnished by the Government. Prior to submitting an offer, it is the responsibility of the bidder/offeror to verify the dimensions, sizes, and shapes in materials provided by the Government. Where practical, the Government will make the vessel available for inspection prior to bid opening or the date for receipt of proposals. If the contractor, as a result of inspection or otherwise, discovers any error in the sketches, drawings, plans or specifications, it shall immediately inform the Contracting Officer of the error and proceed in accord with instructions received from the Contracting Officer. The Government is not liable for any claims or charges resulting from additional work performed by the contractor as a result of a patent ambiguity in the sketches, drawings, plans or specifications that was not brought to the attention of the Contracting Officer. The contractor shall be responsible for the correctness of the shape, sizes and dimensions of parts furnished by the contractor under the contract. (j) The contractor shall at all times keep the site of the work on the vessel free from accumulation of waste material or rubbish caused by contractor employees or the work, and at the completion of the work shall remove all rubbish from and about the site of the work and shall leave the work and its immediate vicinity "broom-clean" unless more exactly specified in this contract. (k) While in drydock or on a marine railway, the contractor shall be responsible for the closing, before the end of working hours, of all valves and openings upon which work is being done by its workers when such closing is practicable. The contractor shall establish a list and keep the COR cognizant of the closure status of all valves and openings upon which the contractor's workers have been working. (l) Without additional expense to the Government, the contractor shall employ specialty subcontractors where required by the specifications or when necessary for satisfactory performance of the work. (m)(1) Unless otherwise stated in the contract, the contractor shall notify the COR at least 72 hours in advance: (i) Prior to starting inspections or tests; and (ii) When supplies will be ready for Government inspection. (2) Such notification shall be provided either verbally or in writing at the discretion of the COR. (End of clause) 1352.271-77 - Delays (APR 2010) When, during the performance of this contract, the contractor is required to delay the work on a vessel temporarily, due to orders or actions of the Government respecting stoppage of work to permit shifting the vessel, stoppage of hot work to permit bunkering, fueling, embarking or debarking of passengers or loading or discharging of cargo, and the contractor is not given sufficient advance notice or is otherwise unable to avoid incurring additional costs on account thereof, an equitable adjustment may be made in the contract. Any such request for equitable adjustment shall be asserted in writing as soon as practicable after the delay or disruption, but not later than the day of final payment under the contract. (End of clause) 1352.271-78 - Minimization of Delay Due to Government Furnished Property (APR 2010) (a) In order to assure timely performance under this contract, it is imperative that delay in the contract's performance period resulting from late, damaged, or unsuitable Government furnished property be held to an absolute minimum. In order to achieve minimization of delay, it is agreed that: (1) Subject to adjustment as provided in paragraph (b) of this clause, the Government shall deliver each item of Government furnished property to the contractor on or before the date specified in the contract or, if later, in sufficient time for the contractor to meet the contract performance period. (2) The Government may forego furnishing any item of Government property to the contractor. In that event, the contractor shall prepare the vessel in terms of piping, wiring, structure, foundation, ventilation, and any other pre-installation requirements of the item, so that the work on the vessel may continue without delay and disruption resulting from the absence of the item. If the Government does not furnish an item designated as Government furnished property, the contract price may be adjusted accordingly. (b) The delivery or performance dates for the supplies or services to be furnished by the contractor under this contract are based upon the expectation that Government furnished property suitable for use (except for such property furnished "as is") will be delivered to the contractor at the time stated in the specification or, if not so stated, in sufficient time to enable the contractor to meet such delivery or performance dates. If the Government furnished property is not furnished in the time stated in the contract, or, if a date is not specified, and the late delivery does not give the contractor sufficient time to enable the contractor to meet required contract delivery or performance dates, the contractor shall notify the Government in writing of the late delivery. Notification shall include cost and schedule impacts, including delays and disruptions to schedules. This notification shall be submitted as soon as practical or known. (c) The provisions in subsection (b) of this clause and in FAR 52.245-1, if applicable, provide the exclusive remedies to the contractor resulting from delay in delivery of Government furnished property or delivery of such property in a condition not suitable for its intended use. (End of clause) 1352.271-79 - Liability and Insurance (APR 2010) (a) The contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property, in and about the work, and to the vessel or part thereof upon which work is done. (b) The contractor shall be responsible for and make good at its own cost and expense any and all loss of or damage of whatsoever nature to the vessel (or part thereof), its equipment, movable stores and cargo, and Government-owned material and equipment for the repair, completion, alteration of or addition to the vessel in the possession of the contractor, whether at the plant or elsewhere, arising or growing out of the performance of the work, except where the contractor can affirmatively show that such loss or damage was due to causes beyond the contractor's control, was proximately caused by the fault or negligence of agents or employees of the Government, or which loss or damage the contractor by exercise of reasonable care was unable to prevent. However, the contractor shall not be responsible for any such loss or damage discovered after redelivery of the vessel unless the loss or damage is discovered within 90 days after redelivery of the vessel and loss or damage is affirmatively shown to be the result of the fault or negligence of the contractor. To induce the contractor to perform the work for the compensation provided, it is specifically agreed that the contractor's aggregate liability on account of loss of or damage to the vessel (or part thereof), its equipment, movable stores and cargo and Government-owned materials and equipment, shall in no event exceed the sum of $1,000,000.00. As to the contractor, the Government assumes the risk of loss or damage to the Government-owned vessel (or part thereof), its equipment, movable stores and cargo and said Government-owned materials and equipment in excess of $1,000,000.00. This assumption of risk includes but is not limited to loss or damage from negligence of whatsoever degree of the contractor's servants, employees, agents or subcontractors, but specifically excludes loss or damage from willful misconduct or lack of good faith on the part of contractor's personnel, who have supervision or direction of all or substantially all of the contractor's business, or all or substantially all of the contractor's operation at any one plant. However, as to such risk assumed and borne by the Government, the Government shall be subrogated to any claim, demand or cause of action against third persons which exists in favor of the contractor, and the contractor shall, if required, execute a formal assignment or transfer of claims, demands or causes of action. Nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the contractor, nor shall any person (except the contractor) be or become entitled thereby to proceed directly against the Government, or join the Government as a co-defendant in any action against the contractor brought to determine the contractor's liability, or for any other purpose. (c) The contractor indemnifies and holds harmless the Government, its agencies and instrumentalities, and the vessel against all suits, actions, claims, costs or demands (including without limitation, suits, actions, claims, costs or demands resulting from death, personal injury and property damage) to which the Government, its agencies and instrumentalities, or the vessel may be subject or put by reason of damage or injury (including death) to the property or person of anyone other than the Government, its agencies, instrumentalities and personnel, or the vessel, arising or resulting in whole or in part from the fault, negligence, wrongful act or wrongful omission of the contractor, or any subcontractor, its or their servants, agents or employees; provided that the contractor's obligation to indemnify under this paragraph (c) shall not exceed the sum of $1,000,000.00 on account of any one accident or occurrence in respect of any one vessel. Such indemnity shall include, without limitation, suits, actions, claims, costs or demands of any kind whatsoever, resulting from death, personal injury or property damage occurring during the period of performance of work on the vessel or within 90 days after redelivery of the vessel. Any new equipment warranties that extend beyond the 90 days after redelivery of the vessel shall be assigned to the Government upon redelivery of the vessel. With respect to any such suits, actions, claims, costs or demands resulting from death, personal injury or property damage occurring after the expiration of such period, the rights and liabilities of the Government and the contractor shall be as determined by other provisions of this contract and by law; provided that such indemnity shall apply to death occurring after such period which results from any personal injury received during the period covered by the contractor's indemnity as provided herein. (d) The contractor shall, at its own expense, procure, and thereafter maintain such casualty, accident and liability insurance, in such forms and amounts as may be approved by the Contracting Officer, insuring the performance of its obligations under paragraph (c) of this clause. In addition, the contractor shall at its own expense procure and thereafter maintain such ship repairer's legal liability insurance as may be necessary to insure the contractor against its liability as ship repairer in the amount of $1,000,000.00, or the value of the vessel as determined by the Contracting Officer, whichever is the lesser, with respect to each vessel on which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies, however, at the discretion of the Contracting Officer, such insurance need not be procured whenever the job order requires work on parts of a vessel only and the work is to be performed at a plant other than the site of the vessel. Further, the contractor shall procure and maintain in force Worker's Compensation Insurance (or its equivalent) covering its employees engaged in the work and shall ensure the procurement and maintenance of such insurance by all subcontractors engaged in the work. The contractor shall provide evidence of insurance as required by the Government. (e) The contractor shall receive no allowance in the contract price for inclusion of any premium expense or charge for any reserve made on account of self-insurance for coverage against any risk assumed by the Government under this clause. (f) As soon as practicable after the occurrence of any loss or damage, the risk of which the Government has assumed, written notice of the damage shall be given by the contractor to the Contracting Officer. The notice shall contain full particulars of the loss or damage. If claim is made or suit is brought thereafter against the contractor as the result or because of such event, the contractor shall immediately deliver to the Government every demand, notice, summons or other process received by it or its representatives. The contractor shall cooperate with the Government, and, upon the Government's request, shall assist in effecting settlements, securing and giving evidence; obtaining the attendance of witnesses, and other assistance required in the conduct of suits. The Government shall pay to the contractor the expense, other than the cost of maintaining the contractor's usual organization, incurred in this assistance. Except at its own cost, the contractor shall not voluntarily make any payment, assume any obligation or incur any expense not imperative for the protection of the vessel or vessels at the time of the event. (End of clause) 1352.271-80 - Title (APR 2010) (a) Title to all materials and equipment acquired, produced for, or allocated to the performance of this contract and incorporated in or placed on the vessel or any part thereof, shall vest in the Government. (b) The contractor shall assume, without limitation, the risk of loss for any contractor-furnished materials and equipment until final acceptance by the Government of work performed under the contract. (End of clause) 1352.271-82 - Department of Labor Occupational Safety and Health Standards for Ship Repair (APR 2010) The contractor, in performance of all work under the contract, shall comply with the requirements of 29 CFR 1910.15. Nothing contained in this contract shall be construed as relieving the contractor from any obligations which it may have for compliance with the aforesaid regulations. (End of clause) 1352.271-83 - Government Review, Comment, Acceptance and Approval (APR 2010) (a) Documentation, including drawings and other engineering products and reports, required by the contract to be submitted for review, comment, acceptance or approval will be acted upon by the Government within 30 calendar days after receipt by the Government, unless another period of time is specified. (b) The Government shall respond to Condition Reports, as defined in the Specifications, within five (5) working days, unless the Government notifies the contractor that a longer period of time will be required. If the contractor requests a response in less than five (5) working days, the Government will attempt to accommodate the request, but does not guarantee a response in less than the time limits stated above. (c) Review, comment, acceptance or approval by the Government as required under this contract and applicable specifications shall not relieve the contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such review, comment and acceptance or approval. (End of clause) 1352.271-84 - Access to the Vessel (APR 2010) (a) As authorized by the Contracting Officer, a reasonable number of officers, employees and personnel designated by the Government, or representatives of other contractors and their subcontractors shall have admission to the facility and access to the vessel at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis. The contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services reasonable and necessary to perform their duties. All such personnel shall comply with contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security. (b) The contractor further agrees to allow a reasonable number of officers, employees, and designated personnel of offerors on other contemplated work, the same privileges of admission to the contractor's facility and access to the vessel(s) on a noninterference basis, subject to contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security. (End of clause) 1352.271-85 - Documentation of Requests for Equitable Adjustment (APR 2010) (a) For the purpose of this clause, the term "change" includes not only a change made pursuant to a written order designated as a "change order," but also any act or omission to act on the part of the Government where a request is made for equitable adjustment. (b) Whenever the contractor requests or proposes an equitable adjustment to the contract price for a change or an act or omission on the part of the Government, the request shall include a breakdown of the price adjustment in such form and supported by such reasonable detail as the Contracting Officer may request. As a minimum, the contractor shall provide a breakdown of direct labor hours, labor dollars, overhead, material, subcontracts, contingencies and profit for each change and a justification for any extension of the delivery date. (c) Whenever the contractor requests or proposes an equitable adjustment of $100,000 or greater gross (aggregate increases and/or decreases) for a change made pursuant to a written order designated as a "change order," or whenever the contractor requests an equitable adjustment in any amount for any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request: (1) A description of the unperformed work required by the contract before the change which has been deleted by the change and the work deleted by the change that already has been completed in whole or in part. The description shall include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property shall be indicated. A separate description shall be furnished for design and production work. Items of raw material, purchased parts, components, and other identifiable hardware which are made excess by the change, and which are not to be retained by the contractor, are to be listed for later disposition; (2) A description of the work necessary to undo work already completed which has been deleted by the change; (3) A description of the work substituted or added by the change that was not required by the terms of the contract before the change. A list of components and equipment (not bulk material or items) involved should be included. A separate description shall be furnished for design work and production work; (4) A description of any interference or inefficiency encountered in performing the change; (5) A description of disruption attributable solely to the change, which shall include the following information: (i) A specific description of each element of disruption which states how the work has been, or will be, disrupted; (ii) The calendar time period when disruption occurred, or will occur, illustrated via critical path analysis; (iii) The area(s) aboard ship where disruption occurred, or will occur; (iv) The trade(s) disrupted, with a breakdown of man-hours for each trade; (v) The scheduling of trades before, during, and after the period of disruption; (vi) A description of measures taken to lessen the disruptive effect of the change. (6) The delay in delivery attributable solely to the change; (7) A description of other work attributed to the change; (8) A narrative statement of the direct causal relationship between any alleged Government act or omission and the claimed result, cross-referenced to the detailed information required above; and (9) A statement setting forth a comparative enumeration of the amounts "budgeted" for the cost elements, including the materials cost, labor hours, and indirect costs pertinent to the change estimated by the contractor in preparing its proposal(s) for this contract, and the amounts claimed to have been incurred, or projected to be incurred, corresponding to each such "budgeted cost" element. (10) At the time of agreement upon the price of the equitable adjustment, the contractor shall submit a signed Certificate of Current Cost or Pricing Data. (d) Pending execution of a bilateral agreement or the direction of the Contracting Officer pursuant to the Changes clause, the contractor shall proceed diligently with contract performance without regard to the effect of any such proposed change. (End of clause) 1352.271-87 - Changes-Ship Repair (APR 2010) (a) The Contracting Officer may, at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract, in any one or more of the following: (1) Drawings, designs, or specifications, when the supplies to be furnished are to be specially manufactured for the Government in accordance with the drawings, designs, or specifications; (2) Method of shipment or packing; (3) Place of performance of the work; (4) Time of commencement or completion of the work; and (5) Other requirements within the general scope of the contract. (b) If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by the order, the Contracting Officer shall make an equitable adjustment in the contract price, the delivery schedule, or both, and shall modify the contract accordingly. (c) The contractor must submit any proposal for adjustment under this clause within 5 days from the date of receipt of the written order. At the Contracting Officer's discretion, the 5-day period may be shortened. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract. (d) If the contractor's proposal includes the cost of property rendered obsolete or excess by the change, the Contracting Officer shall have the right to prescribe the manner of the disposition of the property. (e) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the contractor from proceeding with the contract as changed. (End of clause) 1352.271-88 - Guarantees (APR 2010) (a) In the event any work performed or materials furnished by the contractor under this contract prove defective or deficient within 60 days from the date of redelivery of the vessel, the contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer. (b) The Government shall be entitled to rely upon any guarantee secured by the contractor or any sub-contractor covering work done or materials furnished which exceeds the 60 day period until its expiration. (c) With respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item. (d) If and when practicable, the Government shall afford the contractor an opportunity to effect such corrections and repairs. (1) If the Contracting Officer determines it is impracticable or is otherwise not advisable to return the vessel to the contractor, or the contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the Contracting Officer may direct that the repairs be performed elsewhere, at the contractor's expense. (2) Where corrections and repairs are to be made by other than the contractor due to non-return of the vessel to the contractor, the contractor's liability may be discharged by an equitable deduction in the price of the contract. (e) The contractor's liability shall only extend for an additional __ day guarantee period on those defects or deficiencies which it corrected. However, this clause does not limit the responsibility or relieve the liability of the contractor under the Liability and Insurance clause. (f) At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the contractor and the Contracting Officer shall agree on an equitable deduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract. (g) The rights and remedies of the Government provided in this clause are in addition to and do not limit any rights afforded to the Government by any other clause of the contract. If a defect or deficiency that exists at the time of redelivery of the vessel was not discovered by a reasonable inspection and is discovered after the expiration of the time frame stated in this clause, it is not subject to the time limitations stated in this clause. (End of clause) 1352.271-89 - Temporary Services (APR 2010) (a) Temporary services are services incidental to the performance of work which are required in the schedule or specifications to be provided by the contractor. Temporary services may include the furnishing of water, electricity, telephone service, toilet facilities, garbage removal, office space, parking places or similar facilities. (b) If performance time is extended due to Government-caused delay, the contractor may request an equitable adjustment for providing temporary services at the rate stated in the Schedule. (End of clause) 1352.271-90 - Insurance Requirements (APR 2010) (a) The contractor shall procure and thereafter maintain the following insurance: (1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271-79. This insurance shall be for $1,000,000.00. (2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies. (3) Full coverage in accordance with the State Worker's Compensation law; and (4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act. (b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number ______ for repair/alteration of (name of vessel) in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (APR 2010) and that each such policy contains the following clause: "It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer." (End of clause) (xvi) Defense Priorities and Allocations Systems (DPAS) and assigned ratings is not applicable. (xvii) Offers shall be submitted electronically via email to joel.heisler@noaa.gov no later than 1700 hrs PST, September 16, 2019. (xviii) Contact Joel Heisler at (541) 867-8763 or joel.heisler@noaa.gov for information regarding this solicitation.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/DOC/NOAA/OMAOMD/NMAN7937-19-01548/listing.html)
- Place of Performance
- Address: NOAA ship Oscar Sette, 1897 Ranger Loop, Ford Island Building 184, Honolulu, Hawaii, 96818, United States
- Zip Code: 96818
- Zip Code: 96818
- Record
- SN05435730-W 20190911/190909230656-37b3ffc0d3895beb386bc17512576abf (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |