FBODaily.com | FedBizOpps: PRESOL | 56 | Dewatering the UTR , Lake Tahoe Basin Management Unit - Additional spec

FBO DAILY - FEDBIZOPPS ISSUE OF MAY 15, 2016 FBO #5287
SOLICITATION NOTICE

56 -- Dewatering the UTR , Lake Tahoe Basin Management Unit - Additional spec

Notice Date: 5/13/2016
Notice Type: Combined Synopsis/Solicitation
NAICS: 532412 — Construction, Mining, and Forestry Machinery and Equipment Rental and Leasing
Contracting Office: Department of Agriculture, Forest Service, R-5, Central CA Acquisitions Service Area, Tahoe N.F., 631 Coyote Street, Nevada City, California, 95959-2250, United States
ZIP Code: 95959-2250
Solicitation Number: AG-9JGP-S-16-0111
Archive Date: 7/15/2016
Point of Contact: Raymond Garleb, Phone: 5304786162
E-Mail Address: rgarleb@fs.fed.us
(rgarleb@fs.fed.us)
Small Business Set-Aside: Total Small Business
Description: Plans Specs Plans SWPPP Wage Determination Fire Plan Combined Solicitation & Synopsis AG-9JGP-S-16-0111 The Department of Agriculture, US Forest Service, Central California Acquisition Services Area, Lake Tahoe Basin Management Unit requires services for Dewatering the Upper Truckee River. This is a combined / solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued. It is the contractor's responsibility to be familiar with the applicable clauses and provisions. The clauses may be accessed in full text at these addresses: https://acquisition.gov/far. This is solicitation no.AG-9JGP-S-16-0111, a Request for Quotations (RFQ) and is a 100% Total Small Business Set-Aside. The primary NAICS code is 532412 Construction, Mining, and Forestry Machinery and Equipment Rental and Leasing. The size requirement for this NAICS code is $32.5 million. The government intends to award a Firm Fixed Price Contract. Closing date of Solicitation is: Jun 13, 2016. Projected Award Date is: Jun 24, 2016 AS PER THE GENERAL SPECIFICATIONS IN ATTACHMENT 1-6 AND THE FOLLOWING ADDITIONAL REQUIREMENTS: Contractor Responsibility: Except as otherwise specified under 1.2 and 1.4, the contractor shall furnish the necessary personnel, supplies and transportation to perform the services and insure that the designated areas present a clean, healthy, orderly and well-kept appearance. Estimated Start Date & Contract Time: Date/Time Start 11 Jul, 2016 Contract Time 95 Days Licenses & Insurance The contractor shall obtain the insurance and licenses listed here; (see also Section L, Notices to Offerors and Respondents). Other: Worker's Compensation Insurance: The Contactor shall provide evidence of Worker's Compensation Insurance or a written explanation as to why the Contractor is exempt from the requirement. NOTE: The Contractor working alone is not required to carry the insurance. This contract is utilizing a primary NAICS code 532412/ 32.5m and a secondary NAICS code 238910/ 15m. An SCA wage determination is provided with the first and primary NAICS. If using the secondary NAICS please use the appropriate Davis Bacon wage determination. ITEM NO. DESCRIPTION UNIT QUANTITY UNIT PRICE TOTAL PRICE 1 Mobilization and Installation, River diversion pumps and piping, D-2 LS 1. $ $ 2 Operate River Diversion Pumps And Piping, D-2. Monthly 1. $ $ 3 Pump Security and alarm system Monthly 2.5 $ $ 4 Mobilize and Install Temporary Diversion Dams and Dewatering Basins. LS 1. $ $ 5 Demobilize All Diversion and Dewatering Systems LS 1. $ $ 6 Provide All Equipment for Spray Field which includes *: 6 Sprinklers (50-75 gpm each), 1500' of Hose, 300' of 6" Alum Pipe, 6" Manifolds, two 25yd Filter Boxes. Monthly 2.5 $ $ 7 Option 1: Mobilization and Installation, River diversion pumps and piping (D-1) LS. $ $ - 8 Option 1: Operate River Diversion pumps and piping (D-1) Monthly. $ - 9 Option 2: Gravity fed piping, mobilize and install (D-1) LS. $ $ - * Note; USFS will use their own 6" pump for spray field.. $ - $ - TOTAL $ NOTES: 1. Responses for quantities less than those listed in the numbered items may be rejected. 2. Responses without prices for each item and sub-item may be rejected. 3) If award is made in excess of $30,000, bonds will be required. (See Section I.) 4) If response is greater than $150,000, include bid bond =20% of the total price. (5) Following are abbreviation definitions from FP-03, Section 109 that may appear in the "Unit" column of the Schedule of Items; AC=Acre, CQ=Contract Quanitity, CY= Cubic Yard, EA=Each, GAL=Gallon, HR=Hour, LF=Linear Foot, LS=Lump Sum, MI=Mile, LB=Pound, SF=Square Foot, SY=Square yard, ST=Station, TON=Ton. CQ and LS will be measured and paid as stated in FP-03, Section 109-02. All other Units will be paid according to FAR clause 52.211-18, Variation in Estimated Quanitity. PRICE SUBMITTED BY: Signature Phone Vendor Name FAX Address Email SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK C.1 SCOPE OF CONTRACT Description of Work: The intent of this contract is to have a contractor divert Upper Truckee River (UTR) flows during implementation of the UTR Reach 5 Restoration Project and install dewatering BMPs in the upland areas surrounding the project area in 2016. First option (option 1) includes, approximately 2,170 ft of temporary river bypass be put in place which includes temporary coffer dams, pumps and pipe to accommodate stream flows of 30 cfs (with an additional 10 cfs capacity to accommodate a potential storm event). Second option (option 2) includes, installation of coffer dams and 2,170 ft of gravity fed pipes. Next, the contractor must install upland dewatering basins in the locations shown on the plan sheets provided. Finally, a second river diversion/bypass approximately 3,055 ft in length must be put in place before the first diversion is removed. The second diversion would be smaller in size, needing to accommodate stream flows of 15 cfs (with an additional 5 cfs capacity to accommodate a potential storm event). In addition, we are asking the contractor to provide us (USFS Staff) with the equipment necessary to operate a discharge water spray field in the dewatering basins. Contractor Responsibility: The Contractor shall provide all equipment, supplies, transportation, labor, and supervision--necessary to complete the project, except for that which the contract clearly states is to be furnished by the Government. C.2 Project Location & Description Location: The project is located on National Forest and California Tahoe Conservancy land just south of South Lake Tahoe, CA in El Dorado County under the direction of the Lake Tahoe Basin Management Unit (LTBMU). Description: Access to the work site will be from 2 locations, across the Lake Tahoe Airport runway and on Highway 50/89, across from Jewel Rd and South of the Lake Tahoe Airport. * Exclusions (non-work areas): *Construction fencing will be in place to protect the non-work areas. Accessibility: * Access in the work area will be on a combination of surfaces including; across the airport runway and on a temporary road constructed by the LTBMU on crane mats, encapsulated roadway, steel plates and native meadow surfaces through the project area meadow. Any prospective contractor desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing from the Contracting Officer soon enough to allow a reply to reach all prospective contractors before the solicitation closing date. Oral explanations or instructions given before the award of a contract will not be binding. C.3 Maps Maps showing the general vicinity and/or specific work areas are included in Section J. Maps are general in nature and are not to be considered as definitively identifying locations. C.4 Estimated Start Date & Contract Time Start: 07/11/2016 and stay in place until 10/15/2016 Time: Approximately 14 weeks. See also Section F C.5 Restrictions on Work. Work may be performed at any time during the period of the contract, except as outlined here. Nothing in this part shall be construed to take away any of the Government's rights under the Suspension of Work Clause (52.242-14). Restrictions are as follows: 1. In accordance with the fire plan, if included in Section J. 2. When the Contracting Officer (or designated representative) determines that adverse weather has made access too dangerous or that continued vehicular travel would cause unacceptable road damage. 3. Scheduled setup and removal of all equipment and supplies will be limited to 7am to 6pm Monday thru Friday. 4. If delays are needed for complete removal of aquatic organisms from the existing channel. C.6 Licenses and Insurance The contractor shall obtain the insurance and licenses listed here; (see also Section L, Notices to Offerors and Respondents). MSPA Card (Form WH510): This contract [ ] does [ x ] does not require the contractor to be registered with the US Department of Labor as a Farm Labor Contractor. The Contractor shall provide a current Form WH510 or legible copy. Other: NONE C.7 Camping and Housing Camping is not permitted in US Forest Service campgrounds. Contractor [ ] will [X] will not be permitted to camp elsewhere on US Forest Service land. Camping on Forest Service land is not a right; permission may be revoked for failure to comply with the terms of the permit. (See also Section H, Camping Permit Compliance) C.8 Technical Requirements 1) The entire flow of the Upper Truckee River (UTR) must bypass the Project site by way of two separate diversions. The Contractor will install temporary dams on the UTR sufficient to capture all stream flow as well as two back to back downstream dams at the bottom of the project to control backwater. • By July 11th, stream flow is expected to be 30 cfs or less for the 1st diversion (D-1), pumps and piping will be used (option 1). Under the option 1 scenario, an additional 10 cfs capacity will be required to accommodate a potential storm event. If flows are higher than expected, at the LTBMU's discretion the contractor would install the temporary dams and piping, and the LTBMU would initiate a gravity diversion option rather than pumping (option 2). D-1 will be put in place starting the week of July11, 2016 and stay in place for 5-7 weeks. • The 2nd diversion (D-2) will be installed late enough in the season that flows are expected to be 15 cfs, this diversion will be pumped and piped. An additional 5 cfs capacity will be required for this diversion to accommodate a potential storm event. D-2 will be installed approximately Aug 22, 2016, and stay in place for 4-6 weeks. • Both water diversions must operate 24 hours a day until end of contract terms (or an earlier date specified by the LTBMU). • Contractor will be responsible for installation of all instream flow dissipaters at the outlet of each diversion. Contractor shall provide specifications for flow dissipaters for LTBMU approval. 2) Sound attenuation is required on all pumps and motors used on the project site. 3) Scheduled setup and removal of all equipment and supplies will be limited to Monday through Friday from 7am to 6pm. 4) Security fencing/personnel will be required around all vulnerable pumps and equipment to insure dewatering/diversion is not interrupted and resources are protected. • Contractor shall provide a contingency plan in the event of system failure. 5) Contractor will be allowed two weeks starting no earlier than 07/11/2016 to install and activate the first diversion system. • Access for installing the first diversion will be provided through/across the Lake Tahoe airport runway (which will require a designated vehicle escort) and along a temporary access road constructed by the LTBMU on the meadow surface. o The number of trips into the site across the airport runway shall be minimized to the extent feasible. • Timing of 1st Diversion (D-1) installation will depend on river flows, anticipated to be approximately July 11th. • The 1st diversion (D-1) will need to be left in place until after the 2nd diversion (D-2) is installed. 6) Exact timing of the 2nd diversion installation is currently unknown, however the contractor will be provided 2 week notice prior to activating the diversion to establish the dam and divert full UTR flows. 7) For both diversions: • The diversion dam installations and removal shall follow the guidance provided in the design plans and the technical specifications. • The LTBMU will pump and discharge water encountered within the dewatered reach of the river while the diversion is in place (i.e. groundwater seepage). • The LTBMU will conduct aquatic organism salvage and removal in the existing channel during each diversion installation, which must be completed prior to full diversion activation. o Metered flows into the channel downstream of the coffer dam would be required to maintain some flow for aquatic organism salvage, and to conduct channel flushing. For the pumped diversion(s), a wye fitting shall be installed near the upstream end of the diversion pipes. o During this time, the diversion system will be required to be tested for leaks before full channel diversion. o Contractor will need to coordinate closely with the LTBMU during aquatic organism salvage and relocation efforts, and possibly will need to delay the full river diversion to enable the crew to get the remaining organisms out of the river prior to diverting the entire river flow. • For protection of aquatic organisms and to prevent the spread of aquatic invasive species and pathogens: o All equipment and vehicles used in a waterbody during project implementation shall be inspected and free of invasive species prior to implementation. o Use screening devices for water drafting pumps to avoid impacts to aquatic species. o Ensure that field gear (waders, float tubes, etc.) is cleaned, decontaminated, and/or fully dried prior to entering or moving between aquatic habitats. o To minimize the risk of spreading potential aquatic pathogens and/or diseases through aquatic systems, all field gear (footwear, nets, etc.) that comes in contact with water shall be disinfected using a 0.016% solution of quaternary ammonia. 8) Contractor will be responsible for construction/installation and demobilizing of the Upland Dewater Basin (per sheet C-5 of the engineering plans and technical specifications). Upland Dewater Basin North (3.4 acres) and Dewater Irrigation Cell 6 (1.8 acres) will be required. Upland Dewater Basin North and Dewater Irrigation Cell 6 will be constructed immediately after installation of the first diversion (D-1) and completion of access road construction. Impermeable barrier fence (or approved equivalent) will be installed at the downslope perimeter of each of the Dewatering areas. 9) The contractor will be responsible for removal of both diversions and coffer dams at the completion of project activities in each respective area. Timing of removal of each diversion will depend on project progress. The contractor will be provided 1 week notice prior to needing each diversion demobilized. 10) The contractor will provide all the equipment necessary for our staff to assemble and operate a spray field in the dewatering basins. Items needed would include two 25yd filter boxes (which we could attach our 6" pump to), 300' of 6" alum pipe, 6" manifolds, six sprinklers on tripods (50-75gpm each), and 1500' of hose to supply the sprinklers. 11) Quotes should include make and model numbers for all mechanical equipment proposed for use to accommodate the flow capacities described above for each diversion. SECTION E--INSPECTION AND ACCEPTANCE E.1 FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov/far/ FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES 52.246-2 Inspection of Supplies--Fixed-Price (AUG 1996) E.2 Government Inspections Government inspections are for the purpose of satisfying the Government that the supplies/services are acceptable and do not relieve the Contractor of the responsibility for maintaining quality control. E.3 Acceptance Work on this contract will be deemed acceptable when the processes and/or deliverables conform to the contract requirements. SECTION F--DELIVERIES OR PERFORMANCE FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES 52.242-14 Suspension of Work (APR 1984) F.1 Work Timing The Contractor shall begin work within 5 calendar days after the effective date of the Notice to Proceed and shall prosecute the work at a rate that will result in completion of all work within the following time frame: 11 July thru 14 Oct or 95 days Failure to begin work on schedule will make the contract subject to termination for default. Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time. NOTE: it is highly recommended that all deliveries be made prior to the 2nd week (18 July) of the performance period. F.2 Winter Shutdown When winter weather sets in and the continuation of work is impractical, the Contracting Officer may authorize a total suspension until such time as work can proceed. During the period of total suspension, the calendar days elapsed will not be charged against the contract time. SECTION G--CONTRACT ADMINISTRATION DATA G.1 Pre-work Pre-work conference. Before work begins on this contract, a pre-work conference will be held to discuss the contract--especially the specifications, labor provisions, plan of work, and selected standard clauses. The pre-work meeting should be attended by an officer of the firm or someone designated in writing to act on behalf of the firm. The pre-work meeting may be waived at the discretion of the Contracting Officer. Notice to Proceed. A. [x] No work may begin on this contract until the Contracting Officer has issued a Notice to Proceed. G.2 Payment Payments. Payment will be made for fully acceptable work at the prices bid in the schedule of items. Payment will be made monthly. Contract Release. Before final payment will be made the Contractor shall sign a release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically accepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of 1940 (31 U.S.C. 3727 and 41 U.S.C. 15). Invoices. A. [ ] Payment will be processed using Form FS-6300-30, Contract Pay Estimate and Invoice, prepared by the C.O.R. The Contractor need not submit any other invoice, nor is Contractor required to sign any invoice except the last. B. [x] Payment will be made from Contractor's invoice submitted through IPP. G.3 GOVERNMENT-FURNISHED PROPERTY The Government will provide the following item(s) of Government property to the Contractor for use in the performance of this contract. This property shall be used and maintained by the Contractor in accordance with the provisions of the "Government Property" FAR clause contained elsewhere in the contract. G.4 Invoices Invoices Payment will be made from the contractor's invoice. All invoices are to be submitted via the electronic Invoice Processing Platform (IPP). This is a mandatory requirement initiated by the U.S. Department of Treasury and you can find more information at this website https://www.ipp.gov/index.htm. There is no pre-award registration. After award of a contract, please make sure that your company registers promptly at https://www.ipp.gov/vendors/enrollment-vendors.htm to establish your account. PRIOR to starting the IPP enrollment process, please verify that the point of contact's (POC's) email address is up to date in your company's System for Award Management (SAM) account at www.sam.gov and that any recent update(s) have been allowed time to process resulting in an "Active" status on the SAM account. The one-time enrollment in IPP means a series of emails will be sent to the SAM POC. If you have questions on the IPP enrollment process, the help desk phone number is 1-866-973-3131. SECTION H-SPECIAL CONTRACT PROVISIONS H.1 Emergencies Fire Plan [ ] See Section J, Fire Plan [x] Not applicable; however, Contractors are required to comply with State law during fire season. H.2 Superintendence by Contractor The name and the specific authorities of the foreman or superintendent must be designated in writing to the Contracting Officer. The Contractor may use his/her own prepared letterhead stationery or a "Designation of Contractor's Representative" form available from the Contracting Officer. If the Contractor or the designee is not present when work is being performed on the contract, a Suspend Work Order may be issued with contract time continuing to run. The Contractor shall have a person on-site that is fully conversant in the English language. H.3 Camping Permit Compliance Contractor shall comply with all terms and conditions of any camping permit issued to allow use of premises. Any non-compliance will result in suspension of work until compliance is achieved. H.4 Archaeological and Historic Sites Location of known archaeological, historic, or pre-historic materials--such as Amerind artifacts and/or historic mining, logging, or fur trapping remains protected by the American Antiquities Act (l6 USC 433)--will be identified for the contractor before work commences. H.5 Spill Plan If the total oil or oil products storage exceeds 1,320 gallons or if any single container exceeds a capacity of 660 gallons, the Contractor shall prepare and implement a Spill Prevention and Countermeasures (SPCC) Plan. Such plan shall meet applicable EPA requirements (40 CFR 112), including certification by a registered professional engineer. The Contractor under the direction of the Contracting Officer, or in the absence of said officer, acting independently, shall immediately take action to contain and clean up, without expense to the Government, all petroleum products spills on or in the vicinity of the project which are caused by the Contractor's employees directly or indirectly as a result of contract operations. The Contractor may be held liable for all damages and costs of additional labor, subsistence, equipment, supplies, and transportation deemed necessary by the Government for the containment and cleanup of petroleum products spills caused by Contractor's employees or resulting from contract operations. The Contractor shall immediately report all petroleum products spills to the Contracting Officer. H.6 Equipment Cleaning All off-road equipment used on this project shall be washed before moving into the project area so that the equipment is free of soil, seeds, vegetative material, or other debris that could contain or hold seeds of noxious weeds. "Off-road equipment" includes all logging and construction equipment and such brushing equipment as brush hogs, masticators, and chippers; it does not include log trucks, chip vans, service vehicles, water trucks, pickup trucks, and similar vehicles not intended for off-road use. Equipment will be considered clean when visual inspection does not reveal soil, seeds, plant material, or other such debris. Disassembly of equipment components or specialized inspection equipment is not required. Contractor shall notify the Contracting Officer at least five days in advance of moving equipment in so that arrangements can be made for inspection. If the project area is known to contain noxious weeds, the equipment shall be cleaned before moving to other Forest Service system lands which do not contain noxious weeds. SECTION I: CONTRACT TERMS AND CONDITIONS COMMERCIAL ITEMS FAR 52.212-4 (DEC 2014 (a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights- (1) Within a reasonable time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include- (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, contract line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR Part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment.- (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall- (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the- (A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected contract line item or subline item, if applicable; and (D) Contractor point of contact. (ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer. (6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract. (iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if- (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days; (B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or (C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates: (A) The date fixed under this contract. (B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on- (A) The date on which the designated office receives payment from the Contractor; (B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or (C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor. (vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or (2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination. (k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) The schedule of supplies/services. (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause; (3) The clause at 52.212-5. (4) Addenda to this solicitation or contract, including any license agreements for computer software. (5) Solicitation provisions if this is a solicitation. (6) Other paragraphs of this clause. (7) The Standard Form 1449. (8) Other documents, exhibits, and attachments. (9) The specification. (t) System for Award Management (SAM). (1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (2)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in FAR Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to (A) change the name in the SAM database; (B) comply with the requirements of Subpart 42.12; and (C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract. (3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov. (u) Unauthorized Obligations (1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (i) Any such clause is unenforceable against the Government. (ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an "I agree" click box or other comparable mechanism (e.g., "click-wrap" or "browse-wrap" agreements), execution does not bind the Government or any Government authorized end user to such clause. (iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. (v) Incorporation by reference. The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract. ADDENDUM TO FAR 52.212-4 The following clauses are hereby incorporated by reference or full text as appropriate: 52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991) 52.236-13 ACCIDENT PREVENTION (NOV 1991) FAR 52.237-1 SITE VISIT (APR 1984) Offerors or quoters are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award. A site visit will be conducted at the project location on 24 May 2016 at 1:00 PM local times. LANDSCAPE PRESERVATION The Contractor shall give attention to the effect of contract operation upon the landscape, shall take care to maintain natural surroundings undamaged, and shall conduct the work at all times in compliance with the following requirements. a. Prevention of the Landscape Defacement. The Contractor shall not remove, deface, injure, or destroy trees, shrubs, lawns, or other natural features or any other improvements in the work area unless specifically authorized by the Contracting Officer. Unless otherwise provided herein, the Contractor shall confine contract operations to within the areas designated in contract documents. b. Protection of Streams, Lakes, and Reservoirs. The Contractor shall take sufficient precautions to prevent pollution of streams, lakes, small ponds, and reservoirs with fuels, oils, bitumens, calcium chloride, silt, or other harmful materials. Mechanical equipment shall not be operated in live streams without written approval of the Contracting Officer. AGAR 452.236-72 USE OF PREMISES (NOV 1996) a. Before any camp, quarry, borrow pit, storage, detour, or bypass site, other than shown on the drawings, is opened or operated on USDA land or lands administered by the USDA, the Contractor shall obtain written permission from the Contracting Officer. A camp is interpreted to include a camp site or trailer parking area of any employee working on the project for the Contractor. b. Unless accepted elsewhere in the contract, the Contractor shall (i) provide and maintain sanitation facilities for the work force at the site and (ii) dispose of solid waste in accordance with applicable Federal, State, and local regulations. AGAR 452.236-74 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION (NOV 1996) A. Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.). B. Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged. C. Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer. AGAR 452.236-77 EMERGENCY RESPONSE (NOV 1996) A. Contractor's Responsibility for Fire Fighting 1. The Contractor, under the provisions of FAR clause 52.236-9, PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES AND IMPROVEMENTS, shall immediately extinguish all fires on the work site other than those fires in use as a part of the work. 2. The Contractor may be held liable for all damages and for all costs incurred by the Government for labor, subsistence, equipment, supplies and transportation deemed necessary to control or suppress a fire set or caused by the Contractor or the Contractor's agents or employees. B. Contractor's Responsibility for Notification in Case of Fire The Contractor shall immediately notify the Government of any fires sighted on or in the vicinity of the work site. C. Contractor's Responsibility for Responding to Emergencies When directed by the Contracting Officer, the Contractor shall allow the Government to temporarily use employees and equipment from the work site or emergency work (anticipated to be restricted to fire fighting). An equitable adjustment for the temporary use of employees and equipment will be made under the Changes clause, FAR 52.234-5. NOTE:* Fire Protection Requirements The Contractor shall comply with the Fire Protection and Suppression Requirements. FINAL CLEANUP Before final acceptance, all areas occupied by the Contractor in connection with the work shall be cleaned of all contractor's rubbish, excess materials, temporary structures, and equipment, and all parts of the work area shall be left in a neat and presentable condition. PUBLIC OFFICIALS NOT PERSONALLY LIABLE There shall be no personal liability upon the Contracting Officer or officer in charge, their agents or employees, for any act performed in the discharge of any duty imposed or the exercise of any power or authority conferred upon them by, or within the scope of the contract, it being understood that in all such matters they act solely as agents and representatives of the Government. DESIGNATION OF CONTRACTING OFFICER'S REPRESENTATIVE The Contracting Officer designates the Contracting Officer's Representative(s) (COR). The COR is responsible for administering the performance of work under this contract. In no event, however, will any understanding, agreement, modification, change order, or other matter deviating from the terms of this contract be effective or binding upon the Government unless formalized by proper contractual documents executed by the Contracting Officer prior to completion of the contract. The Contracting Officer should be informed as soon as possible of any actions or inactions by the Contractor or the Government, which will change the required delivery or completion times stated in the contract, and the contract will be modified accordingly. (This does not apply to individual task assignments which were issued by the COR provided they do not affect the delivery schedule or performance period stated in the contract.) On all matters that pertain to the contract terms, the Contractor must communicate with the Contracting Officer. Whenever, in the opinion of the Contractor, the COR requests effort outside the scope of the contract, the Contractor should so advise the COR. If the COR persists and there still exists a disagreement as to proper contractual coverage, the Contracting Officer should be notified immediately, preferably in writing if time permits. Proceeding with work without proper contractual coverage could result in nonpayment or necessitate submittal of a contract claim. GOVERNMENT-FURNISHED PROPERTY The Government will provide the following item(s) of Government property to the Contractor for use in the performance of this contract. This property shall be used and maintained by the Contractor in accordance with provisions of FAR Clause 52.245-2 "52.245-2 Government Property Installation Operation Services)" hereby incorporated by reference into the contract in accordance with FAR clause 52.252-2 "Clauses Incorporated By Reference" found herein. Item No. Property Description Qty Location Date Available CERTIFICATION OF COMPLIANCE Contractor shall certify compliance with specific fire precautionary measures included in the attached Fire Protection and Suppression Forms. The certification shall be made prior to commencement of work and shall be updated if at any time during performance the conditions change. The Government may conduct verification inspections to ensure Contractor's compliance. REQUIREMENTS RELATED TO VEGETATION MANAGEMENT PROJECTS (a) Applicability In accordance with the Final Environmental Impact Statement (FEIS) for "Managing Competing and Unwanted Vegetation in the Pacific Northwest Region," several requirements are being implemented under our contracts that involve vegetation management. This contract involves work that falls within coverage of the FEIS, and therefore requires compliance with applicable provisions below. These requirements apply to all vegetation management projects within coverage of the FEIS, whether accomplished by manual, mechanical, prescribed fire, biological, or herbicide methods. (b) Reports and Notice Requirements (1) The contractor shall prepare and submit, after work is completed but prior to final payment under this contract, a report which includes: (A) The vegetation management treatment method used; (B) Names of each person who worked on the project, their assignment, training received, dates of actual work, and a list of the protective clothing and equipment used; (C) Details of all exposure incidents, accidents, and/or worker health complaints, if any occurred; (D) If the project involves use of herbicides, the exact identity of the product used, its formulation, manufacturer, mixture, and method of application; and, (E) If the project involves use of herbicides, a certification that the health information required by the ROD as amended was provided to all employees in a language they could understand. (2) The contractor shall provide to its employees (including subcontractor personnel) a copy of a bilingual form entitled, "Health Effects Reporting Form for Vegetation Management Projects in the Pacific Northwest Region". This form is to be provided to employees for voluntary completion and submission to the Government, for reporting injuries or exposures while the employee is performing vegetation management work under this contract. This form may also be completed by any persons, including private citizens and Government employees, who wish to report injuries or exposures as a consequence of the contract work. A copy of this form is included for reference in the attachments of this contract. (c) Restrictions on Personnel Assignments for Herbicide Projects (1) All employees who do not want exposure to the herbicides Glyphosate, Dicamba, Tebuthiuron, Triclopyr, Simazine, Bromacil, Dalapon, Atrazine, or 2,4-D will be given alternate work assignments not involving direct contact with these herbicides. (2) Workers who are hypersensitive to the herbicides used in a project covered by these provisions shall not be used in positions in which they may come into direct contact with the herbicides. Workers who display symptoms of hypersensitivity to herbicides during application shall be removed from direct contact with the herbicides. (d) Requirements to Inform Workers of Potential Health Hazards (1) Prior to beginning any project utilizing the herbicides Glyphosate, Dicamba, Tebuthiuron, Triclopyr, Simazine, Bromacil, Dalapon, Atrazine, or 2,4-D, each worker shall be provided with a copy of the "Methods Information Profile for Herbicides" and the relevant "Herbicide Information Profiles" produced by the Pacific Northwest Region. If the worker cannot read English, the information in these profiles will be explained in a language the worker can understand. (2) Each worker shall sign a statement indicating that she or he has reviewed the material, and either agrees to work on the project as assigned, or requests another assignment. The statements will be provided to the COR prior to commencement of work. (e) Equipment and Clothing Requirements (1) For projects utilizing the herbicides Glyphosate, Dicamba, Tebuthiuron, Triclopyr, Simazine, Bromacil, Dalapon, Atrazine, or 2,4-D, all equipment and clothing required by the ROD as amended in February 1992 shall be on-site prior to commencement of work. (2) The COR will assure compliance with these requirements prior to authorizing commencement of work. (f) Penalties for Non-compliance Failure by the Contractor to comply with these requirements will be grounds for contract termination or other remedies provided under the Default clause and other provisions of this contract. State and Federal health and safety agencies may also have grounds for action in cases of noncompliance with applicable laws, rules, and regulations. (g) Government Not Liable for Accidents and Exposures The Government will not accept any liability for accidents and exposures resulting from work under this contract, except in cases in which it is shown that there was a direct action of the Government or its employees which caused the accident or exposure. Otherwise, the Contractor retains responsibility for accidents and exposures that occur during work under this contract. FAR.52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (DEC 2014) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Dec 2014) (2) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004)"(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] __ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). _x_ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509)). _x_ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) __ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note). __ (5) [Reserved]. __ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). __ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). _x_ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Aug 2013) (31 U.S.C. 6101 note). __ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). __ (10) [Reserved]. __ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). __ (ii) Alternate I (Nov 2011) of 52.219-3. __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). __ (ii) Alternate I (JAN 2011) of 52.219-4. __ (13) [Reserved] _x_ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644). __ (ii) Alternate I (Nov 2011). __ (iii) Alternate II (Nov 2011). __ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). __ (ii) Alternate I (Oct 1995) of 52.219-7. __ (iii) Alternate II (Mar 2004) of 52.219-7. __ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)). __ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2014) (15 U.S.C. 637(d)(4)). __ (ii) Alternate I (Oct 2001) of 52.219-9. __ (iii) Alternate II (Oct 2001) of 52.219-9. __ (iv) Alternate III (Oct 2014) of 52.219-9. __ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011)(15 U.S.C. 644(r)). __ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). __ (20) 52.219-16, Liquidated Damages-Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). __ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f). __ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). __ (23) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)). __ (24) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)). _x_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). __ (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126). _x_ (27) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _x_ (28) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). _x_ (29) 52.222-35, Equal Opportunity for Veterans (Jul 2014)(38 U.S.C. 4212). _x_ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). __ (31) 52.222-37, Employment Reports on Veterans (JUL 2014) (38 U.S.C. 4212). __ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). __ (33) 52.222-54, Employment Eligibility Verification (AUG 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) __ (34)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (35)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O. 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-13. __ (36)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (E.O. 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-14. __ (37) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b). __ (38)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (JUN 2014) (E.O. 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-16. _x_ (39) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) (E.O. 13513). _x_ (40) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C. chapter 83). __ (41)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. __ (ii) Alternate I (May 2014) of 52.225-3. __ (iii) Alternate II (May 2014) of 52.225-3. __ (iv) Alternate III (May 2014) of 52.225-3. __ (42) 52.225-5, Trade Agreements (NOV 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). __ (43) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). __ (44) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). __ (45) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). __ (46) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). __ (47) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _x_ (48) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _x_ (49) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (50) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (51) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). __ (52) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). __ (53)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). __ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] _x_ (1) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). _x_ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). __ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). __ (7) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O.13495). __ (8) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). __ (9) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)). __ (10) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (Executive Order 13658). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509). (ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17. (iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212). (vi) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (vii) 52.222-37, Employment Reports on Veterans (Jul 2014) (38 U.S.C. 4212) (viii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (ix) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). (x) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (xi) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). (xii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). (xiii) 52.222-54, Employment Eligibility Verification (AUG 2013). (xiv) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014) (Executive Order 13658). (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. ADDENDUM TO FAR 52.212-5 The following clause(s) are hereby incorporated by reference or full text as appropriate: 52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON RECYCLED PAPER (MAY 2011) 52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION CONTRACTS (SEPT 2013) (http://www. biopreferred.gov 52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA Alternate 1 (JUL 1995) 52.223-10 WASTE REDUCTION PROGRAM (MAY 2011) 452.237-75 RESTRICTIONS AGAINST DISCLOSURE (FEB 1988) AGAR 452.209-71 ASSURANCE REGARDING FELONY CONVICTION OR TAX DELINQUENT STATUS FOR CORPORATE APPLICANTS - ALTERNATE 1 (FEB 2012) (a) This award is subject to the provisions contained in sections 433 and 434 of the Consolidated Appropriations Act, 2012 (P.L. No. 112-74), Division E, as amended and/or subsequently enacted, regarding corporate felony convictions and corporate federal tax delinquencies. Accordingly, by accepting this award the contractor acknowledges that it - (1) does not have a tax delinquency, meaning that it is not subject to any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, and (2) has not been convicted (or had an officer or agent acting on its behalf convicted) of a felony criminal violation under any Federal law within 24 months preceding the award, unless a suspending and debarring official of the United States Department of Agriculture has considered suspension or debarment of the awardee, or such officer or agent, based on these convictions and/or tax delinquencies and determined that suspension or debarment is not necessary to protect the interests of the Government. (b) If the awardee fails to comply with these provisions, the Forest Service may terminate this contract for default and may recover any funds the awardee has received in violation of sections 433 or 434, amended and/or subsequently enacted. SECTION J LIST OF ATTACHED DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS The attachments listed below form a part of this Request for Quotations and any resultant contract: Attch. Title No. of Pages 1 Wage Determination 2 Fire Plan 3 UTR SWPPP 4 Restoration design plans 5 UTR 5-2 LTBMU gravity diversion 6 UTR 5 100% Spec 05 11 16 NOTE: IN COMPLIANCE WITH THE PAPER REDUCTION ACT, FAR CLAUSES 52.212-3, 52.212-1 AND 52.212-2 AND ADDENDUMS ATTACHED THERETO, WHICH APPLY ONLY TO THE SOLICITATION PHASE, ARE NOT DUPLICATED AFTER CONTRACT AWARD. HOWEVER, THEY ARE INCORPORATED BY REFERENCE INTO THE RESULTING CONTRACT. SECTION K FAR 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS- COMMERCIAL ITEMS (DEC 2014) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website accessed through http://www.acquisition.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (p) of this provision. (a) Definitions. As used in this provision- "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Forced or indentured child labor" means all work or service- (1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation", means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Manufactured end product" means any end product in Federal Supply Classes (FSC) 1000-9999, except- (1) FSC 5510, Lumber and Related Basic Wood Materials; (2) Federal Supply Group (FSG) 87, Agricultural Supplies; (3) FSG 88, Live Animals; (4) FSG 89, Food and Related Consumables; (5) FSC 9410, Crude Grades of Plant Materials; (6) FSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) FSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) FSC 9610, Ores; (9) FSC 9620, Minerals, Natural and Synthetic; and (10) FSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate- (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. "Sensitive technology"- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). "Service-disabled veteran-owned small business concern"- (1) Means a small business concern- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. "Small disadvantaged business concern", consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that- (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by- (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and (2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. "Subsidiary" means an entity in which more than 50 percent of the entity is owned- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. "Veteran-owned small business concern" means a small business concern- (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. "Women-owned small business concern" means a small business concern- (1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program" (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. (b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________. [Offeror to identify the applicable paragraphs at (c) through (p) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.] (c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it __ is, __ is not a small business concern. (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it __ is, __ is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it __ is, __ is not a service-disabled veteran-owned small business concern. (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it __ is, __ is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it __ is, __ is not a women-owned small business concern. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that- (i) It __ is, __ is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It __ is, __ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that- (i) It __ is, __ is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It __ is, __ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it __ is a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________ (10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that- (i) It __ is, __ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and (ii) It __ is, __ is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Representations required to implement provisions of Executive Order 11246- (1) Previous contracts and compliance. The offeror represents that- (i) It __ has, __ has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and (ii) It __ has, __ has not filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that- (i) It __ has developed and has on file, __ has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or (ii) It __ has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American-Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item" "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Supplies." (2) Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g)(1) Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms "Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product," "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," "Free Trade Agreement country," "Free Trade Agreement country end product," "Israeli end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." Other Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Canadian End Products: Line Item No. _______________________________________ _______________________________________ _______________________________________ [List as necessary] (3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Canadian or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (4) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled "Trade Agreements." (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals- (1) __ Are, __ are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) __ Have, __ have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; (3) __ Are, __ are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) __ Have, __ have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). (1) Listed end products. Listed End Product Listed Countries of Origin ___________________ ___________________ ___________________ ___________________ (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] [ ] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. [ ] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) _x_ In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) __ Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Labor Standards(Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [ ] (1) Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror __ does __ does not certify that- (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. [ ] (2) Certain services as described in FAR 22.1003-4(d)(1). The offeror o does o does not certify that- (i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies- (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer Identification Number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN. (3) Taxpayer Identification Number (TIN). o TIN: ________________________________. o TIN has been applied for. o TIN is not required because: o Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; o Offeror is an agency or instrumentality of a foreign government; o Offeror is an agency or instrumentality of the Federal Government. (4) Type of organization. o Sole proprietorship; o Partnership; o Corporate entity (not tax-exempt); o Corporate entity (tax-exempt); o Government entity (Federal, State, or local); o Foreign government; o International organization per 26 CFR 1.6049-4; o Other ________________________________. (5) Common parent. o Offeror is not owned or controlled by a common parent; o Name and TIN of common parent: Name ________________________________. TIN _________________________________. (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations. (1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (2) Representation. By submission of its offer, the offeror represents that- (i) It is not an inverted domestic corporation; and (ii) It is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall e-mail questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation and Certifications. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror- (i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and (iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,000 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf). (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if- (i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products. (p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a DUNS Number in the solicitation. (1) The Offeror represents that it __ has or __ does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates "has" in paragraph (p)(1) of this provision, enter the following information: Immediate owner CAGE code: ____________________. Immediate owner legal name: _____________________. (Do not use a "doing business as" name) Is the immediate owner owned or controlled by another entity: __ Yes or __ No. (3) If the Offeror indicates "yes" in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest-level owner CAGE code: __________________. Highest-level owner legal name: ___________________. (Do not use a "doing business as" name) ADDENDUM TO FAR 52.212-3 The following provision(s) are hereby incorporated by reference or full text as appropriate: 52.223-1 Biobased Product Certification (MAY 2012) 52.223-4 Recovered Material Certification (MAY 2008) AGAR 452.209 - 70 REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX LIABILITY OR A FELONY CONVICTION - ALTERNATE 1 (FEB 2012) (a) Awards made under this solicitation are subject to the provisions contained sections 433 and 434 in the Consolidated Appropriations Act, 2012 (P.L. No. 112-74), Division E, as amended and/or subsequently enacted, regarding corporate felony convictions and corporate federal tax delinquencies. To comply with these provisions, all offerors must complete paragraph (1) of this representation, and all corporate offerors also must complete paragraphs (2) and (3) of this representation. (b) The Offeror represents that - (1) The Offeror is [ ], is not [ ] (check one) an entity that has filed articles of incorporation in one of the fifty states, the District of Columbia, or the various territories of the United States including American Samoa, Federated States of Micronesia, Guam, Midway Islands, Northern Mariana Islands, Puerto Rico, Republic of Palau, Republic of the Marshall Islands, U.S. Virgin Islands. (Note that this includes both for-profit and non-profit organizations.) If the Offeror checked "is" above, the Offeror must complete paragraphs (2) and (3) of the representation. If Offeror checked "is not" above, Offeror may leave the remainder of the representation blank. (2) (i) The Offeror has [ ], has not [ ] (check one) been convicted of a felony criminal violation under Federal or State law in the 24 months preceding the date of offer. (ii) Offeror has [ ], has not [ ] (check one) had any officer or agent of Offeror convicted of a felony criminal violation for actions taken on behalf of Offeror under Federal law in the 24 months preceding the date of offer. (3) The Offeror does [ ], does not [ ] (check one) have any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability. SECTION L FAR 52.212-1 INSTRUCTIONS TO OFFERORS-COMMERCIAL ITEMS (APR 2014) (a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show- (1) The solicitation number; (2) The time specified in the solicitation for receipt of offers; (3) The name, address, and telephone number of the offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (5) Terms of any express warranty; (6) Price and any discount terms; (7) "Remit to" address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and (11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing. (e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions or commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately. (f) Late submissions, modifications, revisions, and withdrawals of offers. (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due. (2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and- (A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or (B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or (C) If this solicitation is a request for proposals, it was the only proposal received. (ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted. (3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer. (g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer. (i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to: GSA Federal Supply Service Specifications Section Address: 470 East L'Enfant Plaza, SW Suite 8100 Washington, DC 20407 Phone: Telephone (202) 619-8925 Fax: Facsimile (202) 619-8978. (ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee. (2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites: (i) ASSIST (https://assist.dla.mil/online/start/). (ii) Quick Search (http://quicksearch.dla.mil/). (iii) ASSISTdocs.com (http://assistdocs.com). (3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by- (i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm); (ii) Phoning the DoDSSPCustomer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or (iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462. (4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance. (j) Data Universal Numbering System (DUNS) Number. (Applies to all offers exceeding $3,000, and offers of $3,000 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "DUNS" or "DUNS+4" followed by the DUNS or DUNS+4 number that identifies the offeror's name and address. The DUNS+4 is the DUNS number plus a 4-character suffix that may be assigned at the discretion of the offeror to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR Subpart 32.11) for the same concern. If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one. An offeror within the United States may contact Dun and Bradstreet by calling 1-866-705-5711 or via the internet at http://fedgov.dnb.com/webform. An offeror located outside the United States must contact the local Dun and Bradstreet office for a DUNS number. The offeror should indicate that it is an offeror for a Government contract when contacting the local Dun and Bradstreet office. (k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov. (l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable: (1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer. (2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror. (3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection. (4) A summary of the rationale for award; (5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror. (6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency. ADDENDUM TO FAR 52.212-1 THE FOLLOWING CLAUSE(S) ARE HEREBY INCORPORATED BY REFERENCE OR FULL TEXT AS APPROPRIATE: FACSIMILE/ ELECTRONIC SUBMISSIONS (SIZE LIMITATIONS) (a) Offerors may submit facsimile or electronic quotes as responses to this solicitation. (b) The telephone number of receiving facsimile equipment is: (530) 478-6126 (only first 20 pages) (c) The email address for electronic quotes is: Rgarleb@fs.fed.us (maximum size 8MB) (d) If any portion of a facsimile quote received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document- (1) The Contracting Officer immediately shall notify the offeror and permit the offeror to resubmit the quote. (2) The method and time for resubmission shall be prescribed by the Contracting Officer after consultation with the offeror; and (3) The resubmission shall be considered as if it were received at the date and time of the original unreadable submission for the purpose of determining timelines, provided the offeror complies with the time and format requirements for resubmission prescribed by the Contracting Officer. (d) The Government reserves the right to make award solely on the facsimile proposal. However, if requested to do so by the Contracting Officer, the potential awardee shall promptly submit the complete original signed quote. INSTRUCTIONS FOR SUBMISSION OF OFFERS AND OTHER INFORMATION (a) General Instructions. Quotes submitted in response to this solicitation shall be furnished in the following format with the numbers of copies as specified below: (1) Quotes shall be submitted in two parts - a technical proposal and a price proposal. Each part shall be separate and complete in itself so that evaluation of one may be accomplished independently of the other. The price quote shall be submitted with the solicitation forms, no breakdown of the unit price is required. The technical proposal must not contain reference to cost; however, resource information (such as data concerning labor hours and categories, materials, subcontracts, etc.) must be contained in the technical proposal so that the contractor's understanding of the statement of work may be evaluated. The form attached titled "Response to Evaluation Factors" is to assist in proposal preparation. Use this form OR include similar information with the technical proposal. (2) Offerors are cautioned that sufficient and detailed information must be presented in their technical proposals to enable the Government to evaluate their proposals fully in accordance with the evaluation and award criteria contained herein. The Government is not obligated to ask for additional information and in the absence of appropriate information; the proposal will be rated deficient. (3) The Government will evaluate Quotes in accordance with FAR Clause 52.212-2 "Evaluation - Commercial Items (OCT 2014)" evaluation criteria as set forth herein. (4) Offerors shall submit their proposal(s) in the following format and the quantities specified: (i) 1 copy of the completed, signed offer (The solicitation package) (ii) 1 copies of the Technical Proposal / Documentation Resulting from the Government's Statement of Objectives (iii) In addition to a successful firm's response to the solicitation, responses to all Evaluation Factors excepting Relevant Past Performance will be incorporated into the resulting contract by reference at time of award and retain the full force and effect as all of the other contractual terms and conditions hold therein. (b) Technical Proposal. 1. Technical Approach Provide an Operations Plan with a general project information narrative that specifically includes the following information. The technical approach should be in as much detail as the offeror considers necessary to fully explain the proposed technical approach or method. The technical proposal should reflect a clear understanding of the nature of the work being undertaken. i. Description of and process. ii. Description of proposed procedures for. iii. Description of the general plan for. iv. Proposed method for managing the listed special requirements. v. Description of the deliverable item(s). vi. Proposed locations and capacity for additional work. vii. How operations will meet any of the other contract standards your firm deems significant. 2. Benefit to the Local Community (CORs - The following are samples that may be used or modified to meet your specific purposes when a significant degree of National Fire Plan or Payments to Counties funding is used.) A Describe how and to what degree hiring or training of Nevada, Plumas, Yuba County residents as employees or as subcontractors would be accomplished. B. Describe how and to what degree materials, supplies, lodging, meals, or incidentals would be purchased within Baker, Union, and Wallowa County. C. Describe how materials removed from Forest Service lands would be marketed and utilized in Baker, Union, and/or Wallowa Counties. *Note: Quoters may enhance their technical proposal by identifying strengths, personnel skills and knowledge, unique capabilities and value adding processes to a contract's services, and other attributes that the Government considers as discriminating factors. However, proposals merely offering to conduct a program in accordance with the requirements of the Government's statement of work, will not be eligible for award. The Contractor must submit an explanation of its proposed technical approach in conjunction with the tasks to be performed in achieving the project objectives. (C) Relevant Past Performance - Offerors shall submit past performance information for their firm and any proposed major subcontractors performing more than 20% of the work. Performance information may be obtained from references provided. The Offerors shall provide Past Performance information" for all relevant projects completed during the past three years and all contracts and subcontracts in progress. The list should include, but is not limited to, contracts and subcontracts similar in nature and complexity to that required by this solicitation. Include contracts with the Federal Government, agencies of state, and local governments, and commercial customers. Each offeror will be evaluated on their performance under existing and prior contracts of a similar nature. Performance information will be used as an evaluation factor against which offerors' relative rankings will be compared to assure best value to the Government. The Government will focus on information that demonstrates quality of performance relative to the size and complexity of the procurement under consideration. The Government may contact references beyond those identified by the offeror to obtain additional information for use in both the responsibility determination and in further evaluation of the offerors's past performance. The Office of Management and Budget (OMB) has authorized Federal agencies to collect past performance information under OMB clearance number 9000-0142. (d) Cost/Price: A firm's completion and submission of Blocks 19 through 24 of the subject solicitation's Standard Form 1449 (Page 1 & 2) constitutes the fulfillment of the Government's price proposal requirements under this solicitation. 52.212-2 -- Evaluation -- Commercial Items (Oct 2014) (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: Technical factors and past performance, when combined, are Equal to the Price. 1. General. Proposals will be evaluated on the basis that the following technical factors are in descending order of importance whereby each factor is more important than the next: (1) Technical Proposal being equal to the Relevant Past Performance 2. Technical Proposal. A firm's Technical Proposal will be evaluated based upon their technical approach to the Performance Work Statement, the related qualifications of the personnel proposed, and how they will benefit the local community. 3. Relevant Past Performance. Past performance is a measure of the degree to which an offeror, as an organization, has: (1) satisfied its customers, and (2) complied with federal, state, and local laws and regulations. The Government will inquire about the following elements, which are all of equal importance in relation to each other, (1) quality of the offeror's work; (2) customer satisfaction; (3) timeliness of the Firm during performance and the final completion of the project; and (4) overall business relations. 4. Cost/Price Evaluation Criterion. The degree of importance of the price will increase with the degree of equality of the proposals in relation to the other factors on which selection is to be based, or when the price is so significantly high as to diminish the value of the technical superiority to the Government. (b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. The award or awards will incorporate written information provided by the offeror(s) and utilized by the Government as the basis for award selection. (c) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s). &emsp; RESPONSE TO EVALUATION FACTORS Name of the firm: Experience of the Firm What contracts has your firm performed which are similar in scope, magnitude, and complexity to this project? (You need not list more than 5.) Name of Project Type of Project Scope/magnitude Work performed for Completion Date What other contracts has your firm performed in the past three years that would show your firm's capability to undertake this project? Name of Project Type of Project Scope/magnitude Work performed for Completion Date If yours is a new firm or has no directly relevant experience, how do you propose to acquire the expertise to perform the contract? (e.g., subcontracting arrangements [list subcontractors and their experience], hiring experts [list key personnel and their experience]) Subcontractor Expertise Experience Key Person Expertise Experience Past Performance Information Whom may we contact concerning your performance on the projects listed above? (If reference is for a subcontractor or key person, identify which subcontractor/key person is referenced.) Name Address Phone FAX e-mail Project(s) Understanding of the Work a) How extensive was your site visit for this project? (e.g., ‘didn't visit;' ‘drove by some areas;' ‘walked each acre.') b) What did the site visit reveal about the comparative difficulty of the project-e.g., the problems that are likely to be encountered during performance? c) How many and what types of workers will be assigned to the project? d) What equipment will you use for this project? e) What is your plan for safety at the job site(s)? Identify the hazards specific to the site(s) and the types of work being performed and how you plan to mitigate the risks-to your workers, FS inspectors, and the public. f) What sequence of work are you planning to ensure timely completion of the project? (i.e., what areas or work processes will be done first? next? last?) g) What contracts do you currently have scheduled to which you will need to commit resources during the period for the performance of this project? Name of Project Type of Project Scope/magnitude Work performed for Phone Completion Date h) The offeror will submit a safety plan for this specific project that will address, among other things, a communications plan, egress of injured workers and protection of the public and Government personnel.
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/USDA/FS/9A63/AG-9JGP-S-16-0111/listing.html)
Place of Performance: Address: Location: The project is located on National Forest and California Tahoe Conservancy land just south of South Lake Tahoe, CA in El Dorado County under the direction of the Lake Tahoe Basin Management Unit (LTBMU)., Description: Access to the work site will be from 2 locations, across the Lake Tahoe Airport runway and on Highway 50/89, across from Jewel Rd and South of the Lake Tahoe Airport. *, South Lake Tahoe, California, 96150, United States; Zip Code: 96150
Record: SN04116455-W 20160515/160513234310-474a66c243ed790d1e27971135eaefe0 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

56 -- Dewatering the UTR , Lake Tahoe Basin Management Unit - Additional spec