FBODaily.com | FedBizOpps: PRESOL | J | Aluminum Welding Repairs to the PIFSC 19’ Safe Boat “Steel Toe” - SF 18

FBO DAILY - FEDBIZOPPS ISSUE OF SEPTEMBER 07, 2014 FBO #4670
SOLICITATION NOTICE

J -- Aluminum Welding Repairs to the PIFSC 19’ Safe Boat “Steel Toe” - SF 18

Notice Date: 9/5/2014
Notice Type: Combined Synopsis/Solicitation
NAICS: 336611 — Ship Building and Repairing
Contracting Office: Department of Commerce, National Oceanic and Atmospheric Administration (NOAA), Western Region Acquisition Division, 7600 Sand Point Way, Northeast, Seattle, Washington, 98115-6349
ZIP Code: 98115-6349
Solicitation Number: WE-133F-14-RQ-1180
Archive Date: 9/27/2014
Point of Contact: STEPHANIE M. GARNETT, Phone: (808) 725-5356
E-Mail Address: STEPHANIE.M.GARNETT@NOAA.GOV
(STEPHANIE.M.GARNETT@NOAA.GOV)
Small Business Set-Aside: Total Small Business
Description: Vendor Information Form SOW SF 18 (i) This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. (ii) The solicitation number for this procurement is WE-133F-14-RQ-1180 and is hereby issued as a request for quotation (RFQ). (iii) The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-76 dated July 25, 2014. (iv) This procurement is 100% set-aside for small business concerns. The associated NAICS code is 336611 with a corresponding small business size standard of 1,000 employees. (v) Contract Line Item Numbers See Attached Standard Form 18 included as a separate attachment on FBO. (vi) Description of Requirements See the Statement of Work which is included as a separate attachment on FBO. (vii) Date(s) and Place(s) of Delivery and Acceptance/FOB Point. Place of Delivery: NOAA/NMFS/PIFSC 1845 Wasp Boulevard, Building 176 Honolulu, HI 96818 All deliveries shall be FOB Destination. All Federal Acquisition Regulation (FAR) clauses listed below are available for download at https://acquisition.gov/far/. (viii) 52.212-1, Instructions to Offerors-Commercial Items (APR 2014) applies to this acquisition. (ix) 52.212-2, Evaluation-Commercial Items (JAN 1999) applies to this acquisition as follows: (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: Factor A - APPROACH AND CAPABILITIES - Corporate and individual qualifications for the work; adequacy of equipment, materials, and facilities proposed; experience with the types of operations identified in the Solicitation. Factor B - PAST PERFORMANCE - Performance by the offerer and its subcontractor(s) as it relates to all solicitation requirements, including the quality of services and products, timeliness of performance, and customer satisfaction; and indication of ability to improve performance through proactive management. Evaluation of this factor will be based on the information contained in the proposal and information provided by references and/or other sources. The Project may evaluate past performance by contacting references and/or other sources. Factor C - PRICE - Although price is the least important evaluation factor, it will not be ignored. The degree of importance of the proposed price will increase with the degree of equality of the proposals in relation to the other factors on which selection is to be based. Factors A and B are considered to be substantially more important than price in this evaluation process. (b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s). (c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. The government reserves the right to make an award to other than the lowest priced offer or if the contracting officer determines that to do so would result in the best value to the government. Note that any and all costs associated with proposal preparation, are the responsibility of the quoter and will not be reimbursed by the government. (x) The quoter must submit a completed copy of the provision at FAR 52.212-3, Offeror Representations and Certifications - Commercial Items (MAY 2014), with its quote. (xi) The clause at FAR 52.212-4, Contract Terms and Conditions - Commercial Items (MAY 2014), applies to this acquisition. (xii) The clause at FAR 52.212-5, Contract Terms and Conditions Required to Implement Statutes or Executive Orders - Commercial Items (JUL 2014) applies to this acquisition. The following clauses under subparagraph (b) apply: (10), (14), (25), (28), (30), (31), (33), (42), (46) and (52). The following clauses under subparagraph (c) apply: (1), (2) (xiii) The following additional clauses are also applicable to this acquisition: Department of Commerce Clauses: 1352.201-70 CONTRACTING OFFICER'S AUTHORITY The Contracting Officer is the only person authorized to make or approve any changes in any of the requirements of this contract, and, notwithstanding any provisions contained elsewhere in this contract, the said authority remains solely in the Contracting Officer. In the event the contractor makes any changes at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract terms and conditions, including price. 1352.209-73 COMPLIANCE WITH THE LAWS (APR 2010) The contractor shall comply with all applicable laws, rules and regulations which deal with or relate to performance in accord with the terms of the contract. 1352.209-74 ORGANIZATIONAL CONFLICT OF INTEREST (APR 2010) (a) Purpose. The purpose of this clause is to ensure that the contractor and its subcontractors: (1) Are not biased because of their financial, contractual, organizational, or other interests which relate to the work under this contract, and (2) Do not obtain any unfair competitive advantage over other parties by virtue of their performance of this contract. (b) Scope. The restrictions described herein shall apply to performance or participation by the contractor, its parents, affiliates, divisions and subsidiaries, and successors in interest (hereinafter collectively referred to as "contractor") in the activities covered by this clause as a prime contractor, subcontractor, co-sponsor, joint venturer, consultant, or in any similar capacity. For the purpose of this clause, affiliation occurs when a business concern is controlled by or has the power to control another or when a third party has the power to control both. (c) Warrant and Disclosure. The warrant and disclosure requirements of this paragraph apply with full force to both the contractor and all subcontractors. The contractor warrants that, to the best of the contractor's knowledge and belief, there are no relevant facts or circumstances which would give rise to an organizational conflict of interest, as defined in FAR Subpart 9.5, and that the contractor has disclosed all relevant information regarding any actual or potential conflict. The contractor agrees it shall make an immediate and full disclosure, in writing, to the Contracting Officer of any potential or actual organizational conflict of interest or the existence of any facts that may cause a reasonably prudent person to question the contractor's impartiality because of the appearance or existence of bias or an unfair competitive advantage. Such disclosure shall include a description of the actions the contractor has taken or proposes to take in order to avoid, neutralize, or mitigate any resulting conflict of interest. (d) Remedies. The Contracting Officer may terminate this contract for convenience, in whole or in part, if the Contracting Officer deems such termination necessary to avoid, neutralize or mitigate an actual or apparent organizational conflict of interest. If the contractor fails to disclose facts pertaining to the existence of a potential or actual organizational conflict of interest or misrepresents relevant information to the Contracting Officer, the Government may terminate the contract for default, suspend or debar the contractor from Government contracting, or pursue such other remedies as may be permitted by law or this contract. (e) Subcontracts. The contractor shall include a clause substantially similar to this clause, including paragraphs (f) and (g), in any subcontract or consultant agreement at any tier expected to exceed the simplified acquisition threshold. The terms "contract," "contractor," and "Contracting Officer" shall be appropriately modified to preserve the Government's rights. (f) Prime Contractor Responsibilities. The contractor shall obtain from its subcontractors or consultants the disclosure required in FAR Part 9.507-1, and shall determine in writing whether the interests disclosed present an actual, or significant potential for, an organizational conflict of interest. The contractor shall identify and avoid, neutralize, or mitigate any subcontractor organizational conflict prior to award of the contract to the satisfaction of the Contracting Officer. If the subcontractor's organizational conflict cannot be avoided, neutralized, or mitigated, the contractor must obtain the written approval of the Contracting Officer prior to entering into the subcontract. If the contractor becomes aware of a subcontractor's potential or actual organizational conflict of interest after contract award, the contractor agrees that the Contractor may be required to eliminate the subcontractor from its team, at the contractor's own risk. (g) Waiver. The parties recognize that this clause has potential effects which will survive the performance of this contract and that it is impossible to foresee each circumstance to which it might be applied in the future. Accordingly, the contractor may at any time seek a waiver from the Head of the Contracting Activity by submitting such waiver. 1352.271-70 INSPECTION AND MANNER OF DOING WORK (APR 2010) (a) All work and material shall be subject to the approval of the Contracting Officer or duly authorized representative. Work shall be performed in accordance with the plans and specifications of this contract as modified by any contract modification. (b) Unless otherwise specifically provided for in the contract, all operational practices of the contractor and all workmanship and material, equipment and articles used in the performance of work shall be in accordance with American Bureau of Shipping "Rules for Building and Classing Steel Vessels", U.S. Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F), U.S. Coast Guard Electrical Engineering Regulations (46 CFR Subchapter J), and U.S. Public Health Service "Handbook on Sanitation of Vessel Construction", in effect at the time of the contract award; and the best commercial maritime practices, except where military specifications are specified, in which case such standards of material and workmanship shall be followed. (c) All material and workmanship shall be subject to inspection and test at all times during the contractor's performance of the work to determine their quality and suitability for the purpose intended and compliance with the contract. In case any material or workmanship furnished by the contractor is found to be defective prior to redelivery of the vessel, or not in accordance with the requirements of the contract, the Government shall have the right prior to redelivery of the vessel to reject such material or workmanship, and to require its correction or replacement by the contractor at the contractor's cost and expense. This Government right is in addition to its rights under any Guarantee clause in this contract. If the contractor fails to proceed promptly with the replacement or correction of such material or workmanship, as required by the Contracting Officer, the Government may, by contract or otherwise, replace or correct such material or workmanship and charge to the contractor the excess cost to the Government. The contractor shall provide and maintain an inspection system acceptable to the Government covering the work specified in the contract. Records of all inspection work by the contractor shall be kept complete and available to the Government during the performance of the contract and for a period of two (2) years after delivery of the vessel to the Government. (d) No welding, including tack welding and brazing, shall be permitted in connection with repairs, completions, alterations, or addition to hulls, machinery or components of vessels unless the welder is, at the time, qualified to the standards established by the U.S. Coast Guard, the American Bureau of Shipping, or the Department of the Navy. The welder's qualifications shall be appropriate for the particular service application, filler material type, position of welding, and welding process involved in the work being undertaken. A welder may be required to re-qualify if the Contracting Officer believes there is a reasonable doubt concerning the welder's ability. Welders' qualifications for this purpose shall be governed by the U.S. Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F). When a welding process other than manual shielded arc is proposed or required, the contractor or fabricator shall submit procedure qualification tests for approval prior to production welding. Procedure qualification tests shall be conducted in accordance with the United States Coast Guard Marine Engineering Regulations and Material Specifications (46 CFR Subchapter F). (e) The contractor shall exercise reasonable care to protect the vessel from fire, and the contractor shall maintain a reasonable system of inspection over the activities of welders, burners, riveters, painters, plumbers and similar workers, particularly where such activities are undertaken in the vicinity of the vessel's fuel oil tanks, magazines or storerooms containing flammable material. A reasonable number of hose lines shall be maintained by the contractor ready for immediate use on the vessel at all times while the vessel is berthed alongside the contractor's pier or in dry dock or on a marine railway. All tanks or bilge areas under alteration or repair shall be cleaned, washed, and steamed out or otherwise made safe by the contractor if and to the extent necessary as required by good marine practice or by current Occupational Safety and Health Administration regulations. The Contracting Officer's Representative (COR) shall be furnished with a "gas free" or "safe for hot work" or "safe for workers" certificate before any hot work or entry is done. Unless otherwise provided in this contract, the contractor shall at all times maintain a reasonable fire watch about the vessel, including a fire watch on the vessel while work is being performed thereon. (f) The contractor shall place proper safeguards and/or effect such safety precautions as necessary, including suitable and sufficient lighting, for the prevention of accidents or injury to persons or property during the prosecution of work under this contract and/or from time of receipt of the vessel until acceptance by the Government of the work performed. (g) Except as otherwise provided in this contract, when the vessel is in the custody of the contractor or in dry dock or on a marine railway and the temperature becomes as low as 35 degrees Fahrenheit, the contractor shall keep all pipelines, fixtures, traps, tanks, and other receptacles on the vessel drained to avoid damage from freezing, or if this is not practicable, the vessel shall be kept heated to prevent such damage. The vessel's stern tube and propeller hubs shall be protected from frost damage by applied heat through the use of a salamander or other proper means, as approved by the COR. (h) Whenever practicable, the work shall be performed in a manner which does not interfere with the berthing and messing of personnel attached to the vessel. The contractor shall ensure that assigned personnel have access to the vessel at all times. It is understood that such personnel will not interfere with the work or the contractor's workers. (i) The Government does not guarantee the correctness of the dimensions, sizes, and shapes shown in any sketches, drawings, plans or specifications prepared or furnished by the Government. Prior to submitting an offer, it is the responsibility of the bidder/offeror to verify the dimensions, sizes, and shapes in materials provided by the Government. Where practical, the Government will make the vessel available for inspection prior to bid opening or the date for receipt of proposals. If the contractor, as a result of inspection or otherwise, discovers any error in the sketches, drawings, plans or specifications, it shall immediately inform the Contracting Officer of the error and proceed in accord with instructions received from the Contracting Officer. The Government is not liable for any claims or charges resulting from additional work performed by the contractor as a result of a patent ambiguity in the sketches, drawings, plans or specifications that was not brought to the attention of the Contracting Officer. The contractor shall be responsible for the correctness of the shape, sizes and dimensions of parts furnished by the contractor under the contract. (j) The contractor shall at all times keep the site of the work on the vessel free from accumulation of waste material or rubbish caused by contractor employees or the work, and at the completion of the work shall remove all rubbish from and about the site of the work and shall leave the work and its immediate vicinity "broom-clean" unless more exactly specified in this contract. (k) While in drydock or on a marine railway, the contractor shall be responsible for the closing, before the end of working hours, of all valves and openings upon which work is being done by its workers when such closing is practicable. The contractor shall establish a list and keep the COR cognizant of the closure status of all valves and openings upon which the contractor's workers have been working. (l) Without additional expense to the Government, the contractor shall employ specialty subcontractors where required by the specifications or when necessary for satisfactory performance of the work. (m)(1) Unless otherwise stated in the contract, the contractor shall notify the COR at least 72 hours in advance: (i) Prior to starting inspections or tests; and (ii) When supplies will be ready for Government inspection. (2) Such notification shall be provided either verbally or in writing at the discretion of the COR. (End of clause) 1352.271-71 METHOD OF PAYMENT AND INVOICING INSTRUCTIONS FOR SHIP REPAIR (APR 2010) (a) The Government will make payment under this contract based on a percentage of completion. The contractor may invoice for the percentage completed for each work item as work progresses. The amount invoiced shall be calculated based on prices stated in the Schedule, as follows: A work item may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that work item have no limitation as to the percentage of completion required before invoicing, but in no event may invoices be submitted more frequently than every 2 weeks, or for amounts less than $10,000, unless it is the final payment. The minimum percentage of completion (25%) to be reached prior to billing each work item may be waived by the Contracting Officer for large dollar work items on a case-by-case basis. (b) Invoices submitted by the contractor which are deemed not proper, in accordance with FAR 52.232-25, will be returned. Invoices shall include: (1) Name and Address of the contractor; (2) DUNS Number; (3) Invoice Date; (4) Contract Number/Modification Number; (5) CLIN/Work Item Number, to include: Description, Quantity, Unit of Measure, Unit Price and Extended Price; (6) Shipping and Payment Terms; and, (7) Contractor Point of Contact, including: Name, Title, Phone Number, and Mailing Address; (8) The percentage of completion for each CLIN/work item identified; (9) Name of the Contracting Officer ; (10) Ship name; (11) The overall percentage and dollar amount previously billed, currently billed and unbilled. (c) When invoicing for changed work, the contractor shall identify it as a contract change and shall identify the modification authorizing the change, and the CLIN/Work Item associated with the change. (d) All items of work invoiced under this contract will be verified and confirmed by the Contracting Officer's Representative as accurate and complete and approved by the designated billing office before payment will be made. (e) Mail the original invoice to: [insert] (f) The contractor's final invoice submitted under the contract must be marked as follows: "THIS INVOICE CONSTITUTES THE FINAL INVOICE-UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER ________." (To be assigned at contract award) (End of clause) 1352.271-72 ADDITIONAL ITEM REQUIREMENTS (AIR)-GROWTH WORK (APR 2010) (a) This clause applies to Additional Item Requirements (AIR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes-Ship Repair clause or mutually agreed upon by the parties. The contractor shall perform AIR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The AIR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling. The estimated quantity of labor hours and handling fees represent the Government's best estimate for growth that may be required throughout the contract performance period. All growth work shall be paid at the prices stated in the Schedule. (b) The contractor shall take into account the potential for ordering all estimated AIR quantities in developing the Production Schedule. The ordering of any portion of the AIR quantities does not in itself warrant an extension to the original contract completion date; however, for planning purposes, the Government anticipates ordering AIR in accordance with the following schedule: (1) No more than 75% of the hours during the first half of the contract period of performance. (2) No more than 50% of the hours during the third quarter of the contract period of performance. (3) No more than 30% of the hours during the fourth quarter of the contract period of performance. (c) The AIR labor rate shall be a flat, hourly rate to cover the entire effort and shall be burdened to include: (1) Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production: Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging. (2) Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include: Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire Watch, General Labor (including general support of journeyman tasks), Cleaning (including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making). (d) Additional Item Requirements do not include replacement work performed pursuant to the Inspection and Manner of Doing Work or Guarantees clauses. (e) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause. (f) The contractor shall submit to the Contracting Officer the following information in all AIR proposals: (1) Number of labor hours estimated; broken down by specific direct production labor category. (2) Material estimates, individually broken out and priced. When requested by the Contracting Officer, material quotes shall be provided. (3) Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer. (4) Material/subcontractor handling fee and the basis for the fee. (g) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed. (End of clause) 1352.271-73 SCHEDULE OF WORK (APR 2010) (a) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within five (5) working days of the vessel's arrival at the contractor's facility: (1) Production Schedule. (2) Work Package Network. (3) Total Manpower Loading Curve. (4) Trade Manning Curves. (5) Subcontracting List. (b) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors. (c) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than five (5) calendar days) from the Production Schedule shall be immediately brought to the attention of the Contracting Officer and COR. (d) Any unauthorized deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance, including, but not limited to, liquidated damages. (End of clause) 1352.271-76 PERFORMANCE (APR 2010) (a) The contractor shall not commence work until a notice to proceed has been issued by the Contracting Officer. (b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract. (c) Without additional charge to the Government, and without specific requirement in the contract, the contractor shall: (1) Make available, at the facility, to personnel of the vessel while in drydock or on a marine railway, sanitary facilities adequate for the number of personnel using them and acceptable to the Contracting Officer; (2) Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to the vessel; (3) Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and (4) Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for personnel designated by the Government. (d) Except as otherwise provided in the contract, the contractor shall furnish all necessary material, labor, supervision, services, equipment, tools, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work. (e) The contractor shall conduct dock and sea trials of the vessel as required by the contract. Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the contractor and the Government on board to determine whether the work provided by the contractor has been satisfactorily performed. Dock and sea trials not specified which the contractor requires for its own benefit shall not be undertaken by the contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the contractor. The contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials. (End of clause) 1352.271-77 DELAYS (APR 2010) When, during the performance of this contract, the contractor is required to delay the work on a vessel temporarily, due to orders or actions of the Government respecting stoppage of work to permit shifting the vessel, stoppage of hot work to permit bunkering, fueling, embarking or debarking of passengers or loading or discharging of cargo, and the contractor is not given sufficient advance notice or is otherwise unable to avoid incurring additional costs on account thereof, an equitable adjustment may be made in the contract. Any such request for equitable adjustment shall be asserted in writing as soon as practicable after the delay or disruption, but not later than the day of final payment under the contract. (End of clause) 1352.271-79 LIABILITY AND INSURANCE (APR 2010) (a) The contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property, in and about the work, and to the vessel or part thereof upon which work is done. (b) The contractor shall be responsible for and make good at its own cost and expense any and all loss of or damage of whatsoever nature to the vessel (or part thereof), its equipment, movable stores and cargo, and Government-owned material and equipment for the repair, completion, alteration of or addition to the vessel in the possession of the contractor, whether at the plant or elsewhere, arising or growing out of the performance of the work, except where the contractor can affirmatively show that such loss or damage was due to causes beyond the contractor's control, was proximately caused by the fault or negligence of agents or employees of the Government, or which loss or damage the contractor by exercise of reasonable care was unable to prevent. However, the contractor shall not be responsible for any such loss or damage discovered after redelivery of the vessel unless the loss or damage is discovered within 90 days after redelivery of the vessel and loss or damage is affirmatively shown to be the result of the fault or negligence of the contractor. To induce the contractor to perform the work for the compensation provided, it is specifically agreed that the contractor's aggregate liability on account of loss of or damage to the vessel (or part thereof), its equipment, movable stores and cargo and Government-owned materials and equipment, shall in no event exceed the sum of $1,000,000.00. As to the contractor, the Government assumes the risk of loss or damage to the Government-owned vessel (or part thereof), its equipment, movable stores and cargo and said Government-owned materials and equipment in excess of $1,000,000.00. This assumption of risk includes but is not limited to loss or damage from negligence of whatsoever degree of the contractor's servants, employees, agents or subcontractors, but specifically excludes loss or damage from willful misconduct or lack of good faith on the part of contractor's personnel, who have supervision or direction of all or substantially all of the contractor's business, or all or substantially all of the contractor's operation at any one plant. However, as to such risk assumed and borne by the Government, the Government shall be subrogated to any claim, demand or cause of action against third persons which exists in favor of the contractor, and the contractor shall, if required, execute a formal assignment or transfer of claims, demands or causes of action. Nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the contractor, nor shall any person (except the contractor) be or become entitled thereby to proceed directly against the Government, or join the Government as a co-defendant in any action against the contractor brought to determine the contractor's liability, or for any other purpose. (c) The contractor indemnifies and holds harmless the Government, its agencies and instrumentalities, and the vessel against all suits, actions, claims, costs or demands (including without limitation, suits, actions, claims, costs or demands resulting from death, personal injury and property damage) to which the Government, its agencies and instrumentalities, or the vessel may be subject or put by reason of damage or injury (including death) to the property or person of anyone other than the Government, its agencies, instrumentalities and personnel, or the vessel, arising or resulting in whole or in part from the fault, negligence, wrongful act or wrongful omission of the contractor, or any subcontractor, its or their servants, agents or employees; provided that the contractor's obligation to indemnify under this paragraph (c) shall not exceed the sum of $1,000,000.00 on account of any one accident or occurrence in respect of any one vessel. Such indemnity shall include, without limitation, suits, actions, claims, costs or demands of any kind whatsoever, resulting from death, personal injury or property damage occurring during the period of performance of work on the vessel or within 90 days after redelivery of the vessel. Any new equipment warranties that extend beyond the 90 days after redelivery of the vessel shall be assigned to the Government upon redelivery of the vessel. With respect to any such suits, actions, claims, costs or demands resulting from death, personal injury or property damage occurring after the expiration of such period, the rights and liabilities of the Government and the contractor shall be as determined by other provisions of this contract and by law; provided that such indemnity shall apply to death occurring after such period which results from any personal injury received during the period covered by the contractor's indemnity as provided herein. (d) The contractor shall, at its own expense, procure, and thereafter maintain such casualty, accident and liability insurance, in such forms and amounts as may be approved by the Contracting Officer, insuring the performance of its obligations under paragraph (c) of this clause. In addition, the contractor shall at its own expense procure and thereafter maintain such ship repairer's legal liability insurance as may be necessary to insure the contractor against its liability as ship repairer in the amount of $1,000,000.00, or the value of the vessel as determined by the Contracting Officer, whichever is the lesser, with respect to each vessel on which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies, however, at the discretion of the Contracting Officer, such insurance need not be procured whenever the job order requires work on parts of a vessel only and the work is to be performed at a plant other than the site of the vessel. Further, the contractor shall procure and maintain in force Worker's Compensation Insurance (or its equivalent) covering its employees engaged in the work and shall ensure the procurement and maintenance of such insurance by all subcontractors engaged in the work. The contractor shall provide evidence of insurance as required by the Government. (e) The contractor shall receive no allowance in the contract price for inclusion of any premium expense or charge for any reserve made on account of self-insurance for coverage against any risk assumed by the Government under this clause. (f) As soon as practicable after the occurrence of any loss or damage, the risk of which the Government has assumed, written notice of the damage shall be given by the contractor to the Contracting Officer. The notice shall contain full particulars of the loss or damage. If claim is made or suit is brought thereafter against the contractor as the result or because of such event, the contractor shall immediately deliver to the Government every demand, notice, summons or other process received by it or its representatives. The contractor shall cooperate with the Government, and, upon the Government's request, shall assist in effecting settlements, securing and giving evidence; obtaining the attendance of witnesses, and other assistance required in the conduct of suits. The Government shall pay to the contractor the expense, other than the cost of maintaining the contractor's usual organization, incurred in this assistance. Except at its own cost, the contractor shall not voluntarily make any payment, assume any obligation or incur any expense not imperative for the protection of the vessel or vessels at the time of the event. (End of clause) 1352.271-80 TITLE (APR 2010) (a) Title to all materials and equipment acquired, produced for, or allocated to the performance of this contract and incorporated in or placed on the vessel or any part thereof, shall vest in the Government. (b) The contractor shall assume, without limitation, the risk of loss for any contractor-furnished materials and equipment until final acceptance by the Government of work performed under the contract. (End of clause) 1352.271-81 DISCHARGE OF LIENS (APR 2010) The contractor shall immediately discharge or cause to be discharged any lien or right in rem of any kind, other than in favor of the Government, which at any time exists or arises in connection with work done or materials furnished under the contract. If any such lien or right in rem is not immediately discharged, the Government may discharge or cause to be discharged such lien or right at the expense of the contractor. (End of clause) 1352.271-82 DEPARTMENT OF LABOR OCCUPATIONAL SAFETY AND HEALTH STANDARDS FOR SHIP REPAIR (APR 2010) The contractor, in performance of all work under the contract, shall comply with the requirements of 29 CFR 1910.15. Nothing contained in this contract shall be construed as relieving the contractor from any obligations which it may have for compliance with the aforesaid regulations. (End of clause) 1352.271-83 GOVERNMENT REVIEW, COMMENT, ACCEPTANCE AND APPROVAL (APR 2010) (a) Documentation, including drawings and other engineering products and reports, required by the contract to be submitted for review, comment, acceptance or approval will be acted upon by the Government within 30 calendar days after receipt by the Government, unless another period of time is specified. (b) The Government shall respond to Condition Reports, as defined in the Specifications, within five (5) working days, unless the Government notifies the contractor that a longer period of time will be required. If the contractor requests a response in less than five (5) working days, the Government will attempt to accommodate the request, but does not guarantee a response in less than the time limits stated above. (c) Review, comment, acceptance or approval by the Government as required under this contract and applicable specifications shall not relieve the contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such review, comment and acceptance or approval. (End of clause) 1352.271-84 ACCESS TO THE VESSEL (APR 2010) (a) As authorized by the Contracting Officer, a reasonable number of officers, employees and personnel designated by the Government, or representatives of other contractors and their subcontractors shall have admission to the facility and access to the vessel at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis. The contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services reasonable and necessary to perform their duties. All such personnel shall comply with contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security. (b) The contractor further agrees to allow a reasonable number of officers, employees, and designated personnel of offerors on other contemplated work, the same privileges of admission to the contractor's facility and access to the vessel(s) on a noninterference basis, subject to contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security. (End of clause) 1352.271-85 DOCUMENTATION OF REQUESTS FOR EQUITABLE ADJUSTMENT (APR 2010) (a) For the purpose of this clause, the term "change" includes not only a change made pursuant to a written order designated as a "change order," but also any act or omission to act on the part of the Government where a request is made for equitable adjustment. (b) Whenever the contractor requests or proposes an equitable adjustment to the contract price for a change or an act or omission on the part of the Government, the request shall include a breakdown of the price adjustment in such form and supported by such reasonable detail as the Contracting Officer may request. As a minimum, the contractor shall provide a breakdown of direct labor hours, labor dollars, overhead, material, subcontracts, contingencies and profit for each change and a justification for any extension of the delivery date. (c) Whenever the contractor requests or proposes an equitable adjustment of $100,000 or greater gross (aggregate increases and/or decreases) for a change made pursuant to a written order designated as a "change order," or whenever the contractor requests an equitable adjustment in any amount for any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request: (1) A description of the unperformed work required by the contract before the change which has been deleted by the change and the work deleted by the change that already has been completed in whole or in part. The description shall include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property shall be indicated. A separate description shall be furnished for design and production work. Items of raw material, purchased parts, components, and other identifiable hardware which are made excess by the change, and which are not to be retained by the contractor, are to be listed for later disposition; (2) A description of the work necessary to undo work already completed which has been deleted by the change; (3) A description of the work substituted or added by the change that was not required by the terms of the contract before the change. A list of components and equipment (not bulk material or items) involved should be included. A separate description shall be furnished for design work and production work; (4) A description of any interference or inefficiency encountered in performing the change; (5) A description of disruption attributable solely to the change, which shall include the following information: (i) A specific description of each element of disruption which states how the work has been, or will be, disrupted; (ii) The calendar time period when disruption occurred, or will occur, illustrated via critical path analysis; (iii) The area(s) aboard ship where disruption occurred, or will occur; (iv) The trade(s) disrupted, with a breakdown of man-hours for each trade; (v) The scheduling of trades before, during, and after the period of disruption; (vi) A description of measures taken to lessen the disruptive effect of the change. (6) The delay in delivery attributable solely to the change; (7) A description of other work attributed to the change; (8) A narrative statement of the direct causal relationship between any alleged Government act or omission and the claimed result, cross-referenced to the detailed information required above; and (9) A statement setting forth a comparative enumeration of the amounts "budgeted" for the cost elements, including the materials cost, labor hours, and indirect costs pertinent to the change estimated by the contractor in preparing its proposal(s) for this contract, and the amounts claimed to have been incurred, or projected to be incurred, corresponding to each such "budgeted cost" element. (10) At the time of agreement upon the price of the equitable adjustment, the contractor shall submit a signed Certificate of Current Cost or Pricing Data. (d) Pending execution of a bilateral agreement or the direction of the Contracting Officer pursuant to the Changes clause, the contractor shall proceed diligently with contract performance without regard to the effect of any such proposed change. (End of clause) 1352.271-90 INSURANCE REQUIREMENTS (APR 2010) (a) The contractor shall procure and thereafter maintain the following insurance: (1) Ship contractor's legal liability insurance to insure the risks described in paragraph (b) of clause 1352.271-79. This insurance shall be for $1,000,000.00. (2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of clause 1352.271-79. This insurance shall be for $1,000,000.00 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies. (3) Full coverage in accordance with the State Worker's Compensation law; and (4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act. (b) As evidence that it has obtained the insurance specified in paragraph (a) of this clause, the contractor shall furnish the Contracting Officer with a certificate or certificates executed by an agent of the insurer authorized to execute such certificates. Such certificates shall be furnished prior to commencement of the work. Each certificate shall state that (name of insurer) has insured (name of contractor) awarded contract number ______ for repair/alteration of (name of vessel) in accordance with the Liability and Insurance clause and the Insurance Requirements clause contained herein. Each certificate shall set forth that each policy of insurance represented thereby will expire on (APR 2010) and that each such policy contains the following clause: "It is agreed that in the event of cancellation or any material change in the policy adversely affecting the interest of the Government in this insurance, 30 days prior written notice will be given to the Contracting Officer." (End of clause) The following additional terms and conditions apply: 52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013) (a) Except as stated in paragraph (b) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (1) Any such clause is unenforceable against the Government. (2) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an "I agree" click box or other comparable mechanism (e.g., "click-wrap" or "browse-wrap" agreements), execution does not bind the Government or any Government authorized end user to such clause. (3) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (b) Paragraph (a) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. 52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (DEC 2013) (a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor. (b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act. (c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items. 52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984) (a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause. (b) The use in this solicitation or contract of any clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation. ASSURANCE BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (CLASS DEVIATION) (MARCH 2014) (1) In accordance with Sections 536 and 537 of Division B of Public Law 113-76 Consolidated Appropriations Act, 2014, none of the funds made available by the Consolidated Appropriations Act, 2014 may be used to enter into a contract with any corporation that- (a) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government, or (b) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government. (2) By accepting this award or order, in writing or by performance, the offeror/contractor assures that- (a) The offeror/contractor is not a corporation convicted of a felony criminal violation under a Federal law within the preceding 24 months. (b) The offeror/contractor is not a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreements with the authority responsible for collecting the tax liability. The following provisions apply: 1352.232-70 AGENCY PROTESTS (a) An agency protest may be filed with either: (1) The contracting officer, or (2) at a level above the contracting officer, with the appropriate agency Protest Decision Authority. See 64 FR 16,651 (April 6, 1999). (b) Agency protests filed with the Contracting Officer shall be sent to the following address: National Marine Fisheries Service Pacific Islands Fisheries Science Center 1845 Wasp Boulevard, Building 176 Honolulu, HI 96818. (c) Agency protests filed with the agency Protest Decision Authority shall be sent to the following address: U.S. Department of Commerce Office of Assistant General Counsel for Finance and Litigation Contract Law Division Herbert C. Hoover Building 14th Street and Constitution Avenue NW, Room H5882 Washington DC 20230 FAX: (202) 482-5858 (d) A complete copy of all agency protests, including all attachments, shall be served upon the Contract Law Division of the Office of the General Counsel within one day of filing a protest with either the Contracting Officer or the Protest Decision Authority. (e) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce, Office of the General Counsel Chief, Contract Law Division, Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue, NW Washington, DC 20230. FAX: (202) 482-5858 1352.233-71 GAO AND COURT OF FEDERAL CLAIMS PROTESTS (APR 2010) (a) A protest may be filed with either the Government Accountability Office (GAO) or the Court of Federal Claims unless an agency protest has been filed. (b) A complete copy of all GAO or Court of Federal Claims protests, including all attachments, shall be served upon (i) the Contracting Officer, and (ii) the Contract Law Division of the Office of the General Counsel, within one day of filing a protest with either GAO or the Court of Federal Claims. (c) Service upon the Contract Law Division shall be made as follows: U.S. Department of Commerce Office of the General Counsel Chief, Contract Law Division Room 5893 Herbert C. Hoover Building 14th Street and Constitution Avenue, NW. Washington, DC 20230 FAX: (202) 482-5858 PERIOD OF PERFORMANCE (APR 2010) The period of performance of this purchase order is from the date of award through February 1, 2015. REPRESENTATION BY CORPORATIONS REGARDING AN UNPAID DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (CLASS DEVIATION) (MARCH 2014) (1) In accordance with Sections 536 and 537 of Division B of Public Law 113-76 Consolidated Appropriations Act, 2014, none of the funds made available by the Consolidated Appropriations Act, 2014 funding may be used to enter into a contract with any corporation that- (a) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government, or (b) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government. (2) The Offeror represents that, as of the date of this offer- (a) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (b) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreements with the authority responsible for collecting the tax liability. (xv) Defense Priorities and Allocations System (DPAS) and assigned rating does not apply. (xvi) Quotes are required to be received in the contracting office no later than 10:00 a.m. Hawaii-Aleutian Standard Time (HAST) on September 12, 2014. All quotes must be emailed to the attention of Stephanie.M.Garnett, Contracting Officer at: stephanie.m.garnett@noaa.gov. To be considered, firms must furnish detailed information concerning their capability to provide the required services. Such information shall include (at a minimum): company name, telephone number, address, DUNS number, email address, Standard Form 18, a price proposal and a technical proposal demonstrating the firm's capability to meet the specified requirements. All vendors doing business with the Government are required to be registered in the System for Award Management (SAM) database prior to award of a purchase order. Vendors may register with SAM by calling 1 (866) 606-8220. In order to be eligible to receive an award from this acquisition office, offerors must have a Dun & Bradstreet Number. A Dun & Bradstreet number may be acquired free of charge by contacting Dun & Bradstreet on-line at https://iupdate.dnb.com/iUpdate/companylookup.htm. (xvii) All questions pertaining to this requirement shall be submitted in writing to the attention of Contract Specialist listed above. WD 05-2153 (Rev.-18) was first posted on www.wdol.gov on 08/05/2014 ************************************************************************************ REGISTER OF WAGE DETERMINATIONS UNDER | U.S. DEPARTMENT OF LABOR THE SERVICE CONTRACT ACT | EMPLOYMENT STANDARDS ADMINISTRATION By direction of the Secretary of Labor | WAGE AND HOUR DIVISION | WASHINGTON D.C. 20210 | | | | Wage Determination No.: 2005-2153 Diane C. Koplewski Division of | Revision No.: 18 Director Wage Determinations| Date Of Revision: 07/25/2014 _______________________________________|____________________________________________ States: American Samoa, Hawaii Area: American Samoa Statewide Hawaii Statewide OCCUPATION NOTE: STEVEDORING AND LONGSHOREMEN: Wage rates and fringe benefits can be found on Wage Determination 2000-0085 ____________________________________________________________________________________ **Fringe Benefits Required Follow the Occupational Listing** OCCUPATION CODE - TITLE FOOTNOTE RATE 01000 - Administrative Support And Clerical Occupations 01011 - Accounting Clerk I 14.20 01012 - Accounting Clerk II 15.93 01013 - Accounting Clerk III 17.40 01020 - Administrative Assistant 26.48 01040 - Court Reporter 18.59 01051 - Data Entry Operator I 13.16 01052 - Data Entry Operator II 14.36 01060 - Dispatcher, Motor Vehicle 17.10 01070 - Document Preparation Clerk 13.15 01090 - Duplicating Machine Operator 13.79 01111 - General Clerk I 12.53 01112 - General Clerk II 13.67 01113 - General Clerk III 15.45 01120 - Housing Referral Assistant 23.77 01141 - Messenger Courier 12.47 01191 - Order Clerk I 13.18 01192 - Order Clerk II 14.38 01261 - Personnel Assistant (Employment) I 15.79 01262 - Personnel Assistant (Employment) II 17.88 01263 - Personnel Assistant (Employment) III 19.68 01270 - Production Control Clerk 18.86 01280 - Receptionist 15.40 01290 - Rental Clerk 15.79 01300 - Scheduler, Maintenance 19.05 01311 - Secretary I 19.05 01312 - Secretary II 21.31 01313 - Secretary III 23.77 01320 - Service Order Dispatcher 14.05 01410 - Supply Technician 25.82 01420 - Survey Worker 17.10 01531 - Travel Clerk I 14.78 01532 - Travel Clerk II 15.97 01533 - Travel Clerk III 17.12 01611 - Word Processor I 14.36 01612 - Word Processor II 16.11 01613 - Word Processor III 18.03 05000 - Automotive Service Occupations 05005 - Automobile Body Repairer, Fiberglass 22.19 05010 - Automotive Electrician 22.43 05040 - Automotive Glass Installer 22.00 05070 - Automotive Worker 22.00 05110 - Mobile Equipment Servicer 18.99 05130 - Motor Equipment Metal Mechanic 24.41 05160 - Motor Equipment Metal Worker 22.00 05190 - Motor Vehicle Mechanic 25.65 05220 - Motor Vehicle Mechanic Helper 17.39 05250 - Motor Vehicle Upholstery Worker 20.80 05280 - Motor Vehicle Wrecker 22.00 05310 - Painter, Automotive 23.19 05340 - Radiator Repair Specialist 22.00 05370 - Tire Repairer 13.78 05400 - Transmission Repair Specialist 24.37 07000 - Food Preparation And Service Occupations 07010 - Baker 14.87 07041 - Cook I 13.17 07042 - Cook II 15.29 07070 - Dishwasher 12.05 07130 - Food Service Worker 11.14 07210 - Meat Cutter 18.70 07260 - Waiter/Waitress 12.01 09000 - Furniture Maintenance And Repair Occupations 09010 - Electrostatic Spray Painter 17.41 09040 - Furniture Handler 11.71 09080 - Furniture Refinisher 19.15 09090 - Furniture Refinisher Helper 14.19 09110 - Furniture Repairer, Minor 16.63 09130 - Upholsterer 17.41 11000 - General Services And Support Occupations 11030 - Cleaner, Vehicles 10.89 11060 - Elevator Operator 12.89 11090 - Gardener 16.40 11122 - Housekeeping Aide 14.00 11150 - Janitor 14.00 11210 - Laborer, Grounds Maintenance 13.55 11240 - Maid or Houseman 14.49 11260 - Pruner 12.13 11270 - Tractor Operator 16.43 11330 - Trail Maintenance Worker 13.55 11360 - Window Cleaner 15.25 12000 - Health Occupations 12010 - Ambulance Driver 20.70 12011 - Breath Alcohol Technician 20.70 12012 - Certified Occupational Therapist Assistant 19.67 12015 - Certified Physical Therapist Assistant 18.41 12020 - Dental Assistant 14.80 12025 - Dental Hygienist 30.34 12030 - EKG Technician 26.02 12035 - Electroneurodiagnostic Technologist 26.02 12040 - Emergency Medical Technician 22.19 12071 - Licensed Practical Nurse I 18.51 12072 - Licensed Practical Nurse II 20.70 12073 - Licensed Practical Nurse III 23.09 12100 - Medical Assistant 14.83 12130 - Medical Laboratory Technician 19.74 12160 - Medical Record Clerk 17.82 12190 - Medical Record Technician 19.93 12195 - Medical Transcriptionist 19.74 12210 - Nuclear Medicine Technologist 31.72 12221 - Nursing Assistant I 11.39 12222 - Nursing Assistant II 12.81 12223 - Nursing Assistant III 13.98 12224 - Nursing Assistant IV 15.69 12235 - Optical Dispenser 20.03 12236 - Optical Technician 14.91 12250 - Pharmacy Technician 17.19 12280 - Phlebotomist 15.69 12305 - Radiologic Technologist 29.04 12311 - Registered Nurse I 29.29 12312 - Registered Nurse II 35.82 12313 - Registered Nurse II, Specialist 35.82 12314 - Registered Nurse III 43.34 12315 - Registered Nurse III, Anesthetist 43.34 12316 - Registered Nurse IV 51.94 12317 - Scheduler (Drug and Alcohol Testing) 25.66 13000 - Information And Arts Occupations 13011 - Exhibits Specialist I 19.61 13012 - Exhibits Specialist II 23.29 13013 - Exhibits Specialist III 28.49 13041 - Illustrator I 20.71 13042 - Illustrator II 25.67 13043 - Illustrator III 31.40 13047 - Librarian 28.71 13050 - Library Aide/Clerk 14.17 13054 - Library Information Technology Systems 21.89 Administrator 13058 - Library Technician 17.36 13061 - Media Specialist I 15.86 13062 - Media Specialist II 17.74 13063 - Media Specialist III 19.78 13071 - Photographer I 14.00 13072 - Photographer II 16.54 13073 - Photographer III 19.61 13074 - Photographer IV 23.99 13075 - Photographer V 28.99 13110 - Video Teleconference Technician 20.30 14000 - Information Technology Occupations 14041 - Computer Operator I 17.54 14042 - Computer Operator II 19.62 14043 - Computer Operator III 22.80 14044 - Computer Operator IV 24.81 14045 - Computer Operator V 27.45 14071 - Computer Programmer I (see 1) 27.62 14072 - Computer Programmer II (see 1) 14073 - Computer Programmer III (see 1) 14074 - Computer Programmer IV (see 1) 14101 - Computer Systems Analyst I (see 1) 14102 - Computer Systems Analyst II (see 1) 14103 - Computer Systems Analyst III (see 1) 14150 - Peripheral Equipment Operator 17.54 14160 - Personal Computer Support Technician 24.81 15000 - Instructional Occupations 15010 - Aircrew Training Devices Instructor (Non-Rated) 30.83 15020 - Aircrew Training Devices Instructor (Rated) 37.30 15030 - Air Crew Training Devices Instructor (Pilot) 43.09 15050 - Computer Based Training Specialist / Instructor 30.83 15060 - Educational Technologist 25.80 15070 - Flight Instructor (Pilot) 43.09 15080 - Graphic Artist 22.97 15090 - Technical Instructor 19.66 15095 - Technical Instructor/Course Developer 24.05 15110 - Test Proctor 19.47 15120 - Tutor 19.47 16000 - Laundry, Dry-Cleaning, Pressing And Related Occupations 16010 - Assembler 11.72 16030 - Counter Attendant 11.72 16040 - Dry Cleaner 14.51 16070 - Finisher, Flatwork, Machine 11.72 16090 - Presser, Hand 11.72 16110 - Presser, Machine, Drycleaning 11.72 16130 - Presser, Machine, Shirts 11.72 16160 - Presser, Machine, Wearing Apparel, Laundry 11.72 16190 - Sewing Machine Operator 15.45 16220 - Tailor 16.27 16250 - Washer, Machine 12.67 19000 - Machine Tool Operation And Repair Occupations 19010 - Machine-Tool Operator (Tool Room) 24.08 19040 - Tool And Die Maker 30.25 21000 - Materials Handling And Packing Occupations 21020 - Forklift Operator 20.84 21030 - Material Coordinator 21.89 21040 - Material Expediter 21.89 21050 - Material Handling Laborer 16.89 21071 - Order Filler 13.51 21080 - Production Line Worker (Food Processing) 20.84 21110 - Shipping Packer 15.22 21130 - Shipping/Receiving Clerk 14.69 21140 - Store Worker I 13.23 21150 - Stock Clerk 18.58 21210 - Tools And Parts Attendant 20.84 21410 - Warehouse Specialist 20.84 23000 - Mechanics And Maintenance And Repair Occupations 23010 - Aerospace Structural Welder 28.74 23021 - Aircraft Mechanic I 27.03 23022 - Aircraft Mechanic II 28.74 23023 - Aircraft Mechanic III 30.43 23040 - Aircraft Mechanic Helper 19.51 23050 - Aircraft, Painter 25.27 23060 - Aircraft Servicer 22.63 23080 - Aircraft Worker 24.16 23110 - Appliance Mechanic 21.94 23120 - Bicycle Repairer 15.16 23125 - Cable Splicer 28.39 23130 - Carpenter, Maintenance 30.99 23140 - Carpet Layer 24.86 23160 - Electrician, Maintenance 28.25 23181 - Electronics Technician Maintenance I 26.83 23182 - Electronics Technician Maintenance II 28.69 23183 - Electronics Technician Maintenance III 30.56 23260 - Fabric Worker 20.95 23290 - Fire Alarm System Mechanic 23.46 23310 - Fire Extinguisher Repairer 19.40 23311 - Fuel Distribution System Mechanic 27.68 23312 - Fuel Distribution System Operator 21.58 23370 - General Maintenance Worker 18.45 23380 - Ground Support Equipment Mechanic 27.03 23381 - Ground Support Equipment Servicer 22.63 23382 - Ground Support Equipment Worker 24.16 23391 - Gunsmith I 19.40 23392 - Gunsmith II 22.51 23393 - Gunsmith III 25.64 23410 - Heating, Ventilation And Air-Conditioning 24.07 Mechanic 23411 - Heating, Ventilation And Air Contditioning 25.52 Mechanic (Research Facility) 23430 - Heavy Equipment Mechanic 28.29 23440 - Heavy Equipment Operator 34.11 23460 - Instrument Mechanic 29.96 23465 - Laboratory/Shelter Mechanic 24.07 23470 - Laborer 16.49 23510 - Locksmith 23.45 23530 - Machinery Maintenance Mechanic 24.70 23550 - Machinist, Maintenance 24.58 23580 - Maintenance Trades Helper 14.93 23591 - Metrology Technician I 29.96 23592 - Metrology Technician II 31.76 23593 - Metrology Technician III 33.49 23640 - Millwright 25.64 23710 - Office Appliance Repairer 21.56 23760 - Painter, Maintenance 25.29 23790 - Pipefitter, Maintenance 27.69 23810 - Plumber, Maintenance 25.71 23820 - Pneudraulic Systems Mechanic 25.64 23850 - Rigger 25.64 23870 - Scale Mechanic 22.51 23890 - Sheet-Metal Worker, Maintenance 28.46 23910 - Small Engine Mechanic 20.91 23931 - Telecommunications Mechanic I 27.52 23932 - Telecommunications Mechanic II 28.05 23950 - Telephone Lineman 24.18 23960 - Welder, Combination, Maintenance 25.04 23965 - Well Driller 25.14 23970 - Woodcraft Worker 25.64 23980 - Woodworker 17.67 24000 - Personal Needs Occupations 24570 - Child Care Attendant 11.62 24580 - Child Care Center Clerk 15.14 24610 - Chore Aide 11.40 24620 - Family Readiness And Support Services 16.19 Coordinator 24630 - Homemaker 20.11 25000 - Plant And System Operations Occupations 25010 - Boiler Tender 26.42 25040 - Sewage Plant Operator 21.94 25070 - Stationary Engineer 26.42 25190 - Ventilation Equipment Tender 19.25 25210 - Water Treatment Plant Operator 21.94 27000 - Protective Service Occupations 27004 - Alarm Monitor 18.69 27007 - Baggage Inspector 12.13 27008 - Corrections Officer 21.67 27010 - Court Security Officer 23.28 27030 - Detection Dog Handler 15.35 27040 - Detention Officer 21.67 27070 - Firefighter 23.69 27101 - Guard I 12.13 27102 - Guard II 15.35 27131 - Police Officer I 23.97 27132 - Police Officer II 26.64 28000 - Recreation Occupations 28041 - Carnival Equipment Operator 12.47 28042 - Carnival Equipment Repairer 13.26 28043 - Carnival Equpment Worker 9.93 28210 - Gate Attendant/Gate Tender 15.40 28310 - Lifeguard 15.84 28350 - Park Attendant (Aide) 17.23 28510 - Recreation Aide/Health Facility Attendant 13.19 28515 - Recreation Specialist 21.44 28630 - Sports Official 13.72 28690 - Swimming Pool Operator 17.14 30000 - Technical Occupations 30010 - Air Traffic Control Specialist, Center (HFO) (see 2) 35.77 30011 - Air Traffic Control Specialist, Station (HFO) (see 2) 24.66 30012 - Air Traffic Control Specialist, Terminal (HFO) (see 2) 27.16 30021 - Archeological Technician I 16.98 30022 - Archeological Technician II 19.43 30023 - Archeological Technician III 24.08 30030 - Cartographic Technician 24.08 30040 - Civil Engineering Technician 21.55 30061 - Drafter/CAD Operator I 16.86 30062 - Drafter/CAD Operator II 19.43 30063 - Drafter/CAD Operator III 21.67 30064 - Drafter/CAD Operator IV 26.66 30081 - Engineering Technician I 15.91 30082 - Engineering Technician II 18.64 30083 - Engineering Technician III 22.50 30084 - Engineering Technician IV 29.74 30085 - Engineering Technician V 32.60 30086 - Engineering Technician VI 39.41 30090 - Environmental Technician 22.21 30210 - Laboratory Technician 23.01 30240 - Mathematical Technician 25.78 30361 - Paralegal/Legal Assistant I 18.66 30362 - Paralegal/Legal Assistant II 23.13 30363 - Paralegal/Legal Assistant III 28.30 30364 - Paralegal/Legal Assistant IV 34.23 30390 - Photo-Optics Technician 25.78 30461 - Technical Writer I 22.86 30462 - Technical Writer II 27.96 30463 - Technical Writer III 33.84 30491 - Unexploded Ordnance (UXO) Technician I 22.74 30492 - Unexploded Ordnance (UXO) Technician II 27.51 30493 - Unexploded Ordnance (UXO) Technician III 32.97 30494 - Unexploded (UXO) Safety Escort 22.74 30495 - Unexploded (UXO) Sweep Personnel 22.74 30620 - Weather Observer, Combined Upper Air Or (see 2) 21.67 Surface Programs 30621 - Weather Observer, Senior (see 2) 24.08 31000 - Transportation/Mobile Equipment Operation Occupations 31020 - Bus Aide 12.94 31030 - Bus Driver 18.43 31043 - Driver Courier 14.10 31260 - Parking and Lot Attendant 9.16 31290 - Shuttle Bus Driver 14.98 31310 - Taxi Driver 11.77 31361 - Truckdriver, Light 14.98 31362 - Truckdriver, Medium 17.26 31363 - Truckdriver, Heavy 18.27 31364 - Truckdriver, Tractor-Trailer 18.27 99000 - Miscellaneous Occupations 99030 - Cashier 10.93 99050 - Desk Clerk 18.46 99095 - Embalmer 22.34 99251 - Laboratory Animal Caretaker I 12.41 99252 - Laboratory Animal Caretaker II 17.67 99310 - Mortician 24.57 99410 - Pest Controller 17.33 99510 - Photofinishing Worker 13.86 99710 - Recycling Laborer 19.19 99711 - Recycling Specialist 23.10 99730 - Refuse Collector 17.18 99810 - Sales Clerk 14.39 99820 - School Crossing Guard 15.03 99830 - Survey Party Chief 24.01 99831 - Surveying Aide 13.13 99832 - Surveying Technician 17.99 99840 - Vending Machine Attendant 12.64 99841 - Vending Machine Repairer 15.06 99842 - Vending Machine Repairer Helper 12.64 ____________________________________________________________________________________ ALL OCCUPATIONS LISTED ABOVE RECEIVE THE FOLLOWING BENEFITS: HEALTH & WELFARE: (Hawaii): $1.66 per hour, or $66.40 per week, or $297.73 per month hour for all employees on whose behalf the contractor provides health care benefits pursuant to the Hawaii prepaid Health Care Act. For those employees who are not receiving health care benefits mandated by the Hawaii prepaid Health Care Act, the new health and welfare benefit rate will be $4.02 per hour. VACATION: 2 weeks paid vacation after 1 year of service with a contractor or successor; 3 weeks after 10 years, and 4 after 15 years. Length of service includes the whole span of continuous service with the present contractor or successor, wherever employed, and with the predecessor contractors in the performance of similar work at the same Federal facility. (Reg. 29 CFR 4.173) HOLIDAYS: A minimum of ten paid holidays per year, New Year's Day, Martin Luther King Jr's Birthday, Washington's Birthday, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans' Day, Thanksgiving Day, and Christmas Day. (A contractor may substitute for any of the named holidays another day off with pay in accordance with a plan communicated to the employees involved.) (See 29 CFR 4174) THE OCCUPATIONS WHICH HAVE NUMBERED FOOTNOTES IN PARENTHESES RECEIVE THE FOLLOWING: 1) COMPUTER EMPLOYEES: Under the SCA at section 8(b), this wage determination does not apply to any employee who individually qualifies as a bona fide executive, administrative, or professional employee as defined in 29 C.F.R. Part 541. Because most Computer System Analysts and Computer Programmers who are compensated at a rate not less than $27.63 (or on a salary or fee basis at a rate not less than $455 per week) an hour would likely qualify as exempt computer professionals, (29 C.F.R. 541. 400) wage rates may not be listed on this wage determination for all occupations within those job families. In addition, because this wage determination may not list a wage rate for some or all occupations within those job families if the survey data indicates that the prevailing wage rate for the occupation equals or exceeds $27.63 per hour conformances may be necessary for certain nonexempt employees. For example, if an individual employee is nonexempt but nevertheless performs duties within the scope of one of the Computer Systems Analyst or Computer Programmer occupations for which this wage determination does not specify an SCA wage rate, then the wage rate for that employee must be conformed in accordance with the conformance procedures described in the conformance note included on this wage determination. Additionally, because job titles vary widely and change quickly in the computer industry, job titles are not determinative of the application of the computer professional exemption. Therefore, the exemption applies only to computer employees who satisfy the compensation requirements and whose primary duty consists of: (1) The application of systems analysis techniques and procedures, including consulting with users, to determine hardware, software or system functional specifications; (2) The design, development, documentation, analysis, creation, testing or modification of computer systems or programs, including prototypes, based on and related to user or system design specifications; (3) The design, documentation, testing, creation or modification of computer programs related to machine operating systems; or (4) A combination of the aforementioned duties, the performance of which requires the same level of skills. (29 C.F.R. 541.400). 2) AIR TRAFFIC CONTROLLERS AND WEATHER OBSERVERS - NIGHT PAY & SUNDAY PAY: If you work at night as part of a regular tour of duty, you will earn a night differential and receive an additional 10% of basic pay for any hours worked between 6pm and 6am. If you are a full-time employed (40 hours a week) and Sunday is part of your regularly scheduled workweek, you are paid at your rate of basic pay plus a Sunday premium of 25% of your basic rate for each hour of Sunday work which is not overtime (i.e. occasional work on Sunday outside the normal tour of duty is considered overtime work). HAZARDOUS PAY DIFFERENTIAL: An 8 percent differential is applicable to employees employed in a position that represents a high degree of hazard when working with or in close proximity to ordinance, explosives, and incendiary materials. This includes work such as screening, blending, dying, mixing, and pressing of sensitive ordance, explosives, and pyrotechnic compositions such as lead azide, black powder and photoflash powder. All dry-house activities involving propellants or explosives. Demilitarization, modification, renovation, demolition, and maintenance operations on sensitive ordnance, explosives and incendiary materials. All operations involving regrading and cleaning of artillery ranges. A 4 percent differential is applicable to employees employed in a position that represents a low degree of hazard when working with, or in close proximity to ordance, (or employees possibly adjacent to) explosives and incendiary materials which involves potential injury such as laceration of hands, face, or arms of the employee engaged in the operation, irritation of the skin, minor burns and the like; minimal damage to immediate or adjacent work area or equipment being used. All operations involving, unloading, storage, and hauling of ordance, explosive, and incendiary ordnance material other than small arms ammunition. These differentials are only applicable to work that has been specifically designated by the agency for ordance, explosives, and incendiary material differential pay. ** UNIFORM ALLOWANCE ** If employees are required to wear uniforms in the performance of this contract (either by the terms of the Government contract, by the employer, by the state or local law, etc.), the cost of furnishing such uniforms and maintaining (by laundering or dry cleaning) such uniforms is an expense that may not be borne by an employee where such cost reduces the hourly rate below that required by the wage determination. The Department of Labor will accept payment in accordance with the following standards as compliance: The contractor or subcontractor is required to furnish all employees with an adequate number of uniforms without cost or to reimburse employees for the actual cost of the uniforms. In addition, where uniform cleaning and maintenance is made the responsibility of the employee, all contractors and subcontractors subject to this wage determination shall (in the absence of a bona fide collective bargaining agreement providing for a different amount, or the furnishing of contrary affirmative proof as to the actual cost), reimburse all employees for such cleaning and maintenance at a rate of $3.35 per week (or $.67 cents per day). However, in those instances where the uniforms furnished are made of "wash and wear" materials, may be routinely washed and dried with other personal garments, and do not require any special treatment such as dry cleaning, daily washing, or commercial laundering in order to meet the cleanliness or appearance standards set by the terms of the Government contract, by the contractor, by law, or by the nature of the work, there is no requirement that employees be reimbursed for uniform maintenance costs. The duties of employees under job titles listed are those described in the "Service Contract Act Directory of Occupations", Fifth Edition, April 2006, unless otherwise indicated. Copies of the Directory are available on the Internet. A links to the Directory may be found on the WHD home page at http://www.dol. gov/esa/whd/ or through the Wage Determinations On-Line (WDOL) Web site at http://wdol.gov/. REQUEST FOR AUTHORIZATION OF ADDITIONAL CLASSIFICATION AND WAGE RATE {Standard Form 1444 (SF 1444)} Conformance Process: The contracting officer shall require that any class of service employee which is not listed herein and which is to be employed under the contract (i.e., the work to be performed is not performed by any classification listed in the wage determination), be classified by the contractor so as to provide a reasonable relationship (i.e., appropriate level of skill comparison) between such unlisted classifications and the classifications listed in the wage determination. Such conformed classes of employees shall be paid the monetary wages and furnished the fringe benefits as are determined. Such conforming process shall be initiated by the contractor prior to the performance of contract work by such unlisted class(es) of employees. The conformed classification, wage rate, and/or fringe benefits shall be retroactive to the commencement date of the contract. {See Section 4.6 (C)(vi)} When multiple wage determinations are included in a contract, a separate SF 1444 should be prepared for each wage determination to which a class(es) is to be conformed. The process for preparing a conformance request is as follows: 1) When preparing the bid, the contractor identifies the need for a conformed occupation(s) and computes a proposed rate(s). 2) After contract award, the contractor prepares a written report listing in order proposed classification title(s), a Federal grade equivalency (FGE) for each proposed classification(s), job description(s), and rationale for proposed wage rate(s), including information regarding the agreement or disagreement of the authorized representative of the employees involved, or where there is no authorized representative, the employees themselves. This report should be submitted to the contracting officer no later than 30 days after such unlisted class(es) of employees performs any contract work. 3) The contracting officer reviews the proposed action and promptly submits a report of the action, together with the agency's recommendations and pertinent information including the position of the contractor and the employees, to the Wage and Hour Division, Employment Standards Administration, U.S. Department of Labor, for review. (See section 4.6(b)(2) of Regulations 29 CFR Part 4). 4) Within 30 days of receipt, the Wage and Hour Division approves, modifies, or disapproves the action via transmittal to the agency contracting officer, or notifies the contracting officer that additional time will be required to process the request. 5) The contracting officer transmits the Wage and Hour decision to the contractor. 6) The contractor informs the affected employees. Information required by the Regulations must be submitted on SF 1444 or bond paper. When preparing a conformance request, the "Service Contract Act Directory of Occupations" (the Directory) should be used to compare job definitions to insure that duties requested are not performed by a classification already listed in the wage determination. Remember, it is not the job title, but the required tasks that determine whether a class is included in an established wage determination. Conformances may not be used to artificially split, combine, or subdivide classifications listed in the wage determination.
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/DOC/NOAA/WASC/WE-133F-14-RQ-1180/listing.html)
Record: SN03497408-W 20140907/140905234653-72a066bea57c8b6c83364080c8fe7989 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

J -- Aluminum Welding Repairs to the PIFSC 19’ Safe Boat “Steel Toe” - SF 18