FBODaily.com | FedBizOpps: PRESOL | 20 | Emergency Drydock Repairs CGC Barracuda - SF1449

FBO DAILY - FEDBIZOPPS ISSUE OF APRIL 23, 2014 FBO #4533
SOLICITATION NOTICE

20 -- Emergency Drydock Repairs CGC Barracuda - SF1449

Notice Date: 4/21/2014
Notice Type: Combined Synopsis/Solicitation
NAICS: 336611 — Ship Building and Repairing
Contracting Office: Department of Homeland Security, United States Coast Guard (USCG), USCG Surface Forces Logistics Center (SFLC) Procurement Branch 1, 300 East Main Street, Suite 600, Norfolk, Virginia, 23510-9102, United States
ZIP Code: 23510-9102
Solicitation Number: HSCG80-14-Q-P45H77
Archive Date: 5/10/2014
Point of Contact: Jaime R. Smith, Phone: 7576284646, Susan A. Kreider, Phone: 7576284644
E-Mail Address: Jaime.R.Smith@uscg.mil, susan.a.kreider@uscg.mil
(Jaime.R.Smith@uscg.mil, susan.a.kreider@uscg.mil)
Small Business Set-Aside: Total Small Business
Description: Pricing Data Worksheet Specification for Drydock Repairs FY14 Solicitation Form 1449 NOTICE FOR FILING AGENCY PROTESTS United States Coast Guard Ombudsman Program It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman. Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable). Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester's concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in, writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to: COMMANDANT (CG-9131) U S COAST GUARD OMBUDSMAN PROGRAM FOR AGENCY PROTESTS 2100 2ND ST SW STOP 7112 WASHINGTON DC 20593-7112 The Ombudsman Hotline telephone number is 202-372-3695. COMBINED SYNOPSIS/ SOLICITATION FOR DOCK SIDE REPAIRS FOR USCGC BARRACUDA (WPB-87301) This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart 12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued. The solicitation is issued as a Request for Quotation (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular FAC 2005-72. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 13.5. The NAICS Code is 336611, Ship Building and Repairing with a small business size standard of 1,000 employees. The solicitation number is HSCG80-14-Q-P45H77. CONTRACT ADMINISTRATION: The U.S. Department of Homeland Security, U.S. Coast Guard, Surface Forces Logistic Command, CPD, 300 East Main Street, Suite 600, Norfolk, VA 23510-9112 will perform all contract administration. Communications pertaining to contractual administrative matters shall be addressed to one of the Contracting Officers (KO) listed below. Changes in, or deviations from, the specification or terms and conditions of the contract shall not be effected without written modification to the contract as executed by a USCG SFLC CPD Contracting Officer. Contracting Officer: Susan A. Kreider Telephone #: (757) 628-4644 E-Mail: Susan.A.Kreider@uscg.mil Fax #: (757) 628-4676 Alternate Contracting Officer(s): Any warranted USCG SFLC CPD Contracting Officer Contract Administrator (Contract Specialist): Serves as the point of contact between the Contractor and the Contracting Officer(s); however, this person does not have a warrant that provides the authority to contractually commit the Government. Contract Specialist: Jaime Smith Telephone #: (757) 628-4646 E-Mail: Jaime.R.Smith@uscg.mil Fax #: (757) 628-4676 The Contracting Officer's Representative (COR): Is a Government employee designated in writing by the Contracting Officer to act as a technical advisor for the Contracting Officer for services/items within the scope of the contract. The COR performs functions such as review and/or inspection and acceptance of supplies and services and of a technical nature. A designation letter will set forth the name of the COR and the authorities and limitations of the COR under the contract. This person does not have a warrant that provides the authority to contractually commit the Government or to modify any terms and conditions of a contract. COR: LTJG William Veilleux Telephone #: (733) 973-8905 E-Mail: William.J.Veilleux@uscg.mil REQUIRED DOCUMENT Each quoter shall furnish the information required by the solicitation, which includes: 1. Schedule of Supplies and Services filled out with a cost associated with each CLIN and cost and breakdown as outlined on page 4 2. Past Performance Documentation as outlined on page 25 3. Small Business Self Certification 4. Proof of Insurance (Statement of Coverage from current Insurance carrier) as outlined on page 14 5. Welding Certifications and Procedures 6. Proof of Insurance (Statement of Coverage from current Insurance carrier) 7. Dry Dock Facility and or Dry Dock Cradle ( if applicable) Certification 8. Pre-Award Dry Dock Calculations for US Coast Guard Cutter 87 foot WPB PLACE OF PERFORMANCE The place of performance will be at Contractor's Facility (to be incorporated at time of award). GEOGRAPHIC RESTRICTION: Per U. S. Coast Guard Pacific Area Instruction 3100.1F, the vessel is restricted to the California (San Francisco Bay and South) home port CPBs: United States West Coast San Francisco Bay and South for dry dock repairs. No contract shall be awarded to a facility located outside of this geographic restriction. ANTICIPATED AWARD DATE The anticipated award date is on or about 30 April 2014, however it is subject to change. The government intends to award a fixed priced contract resulting from this solicitation to the responsible vendor whose complete quote, conforming to the solicitation, provides the best and final offer. Work covered by this solicitation shall be completed within fourteen (14) calendar days from the date the vessel becomes available to the Contractor. The availability is scheduled to start on or about 02 May 2014 and end on or about 16 May 2014. An arrival conference normally will be held within 48 hours of the scheduled start date. QUESTIONS AND REQUEST FOR DRAWINGS: The last day to request drawings or ask questions regarding this solicitation is 23 April 2014 at 12:00PM EST. After this date further requests may not be accepted due to time constraints. For questions regarding this solicitation, contact Jaime Smith, Contract Specialist at (757) 628-4646 or Jaime.R.Smitht@uscg.mil QUOTATION DUE DATE Quotations must arrive no later than 01:00 p.m. EST, 25 April 2014. Quotations may be sent via electronic mail (e-mail) to Jaime.R.Smith@uscg.mil, or Quotations may be sent via the US Postal Service or hand delivered to: USCG Surface Forces Logistics Center, Attn: Jaime Smith, 300 East Main Street, Suite 600, Norfolk, VA 23510. As per FAR 52.215-5 FACSIMILE QUOTATIONS (OCT 1997), vendors may submit facsimile quotes as responses to this solicitation. E-mail and Facsimile Quotations are subject to the same rules as paper Quotations. The telephone number for receiving facsimiles is (757) 628-4628. PLEASE NOTE: QUOTATIONS THAT DO NOT INCLUDE ALL REQUIRED DOCUMENTS MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED. DESCRIPTION OF WORK (a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, accessories, consumables, and such other things as are necessary, except as otherwise specified, to perform dock side repairs and alterations to the vessel, in accordance with this solicitation and attached USCGC BARRACUDA (WPB-87301) specification for drydock repairs FY2014, Rev-0, 10 April 2014. (b) Failure to read the specifications in their entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the offeror's risk. All Quotations submitted in response to this solicitation shall stand firm for 60 calendar days from the response date of this solicitation. ALL CONTRACTORS ARE RESPONSIBLE FOR VERIFYING THE RECEIPT OF THEIR QUOTES. PRICING DATA Base Contract Line Item Numbers (CLINs) are marked as "D" for Definitive. Optional CLINs are marked "O" for Optional. Insert unit prices in all CLINs listed in the Schedule unless "NSP" is printed in the Unit Price column for any CLIN. "NSP" in the section means "Not Separately Priced." ITEM DESCRIPTION UNIT PRICE UNIT QTY EXTENDED PRICE D-001 Propulsion Shafts, Remove, Inspect, and Reinstall (D) JOB 1 O-002 Propulsion Shaft, Repair (O) JOB 1 O-003 Propulsion Shaft, Straighten (O) JOB 1 D-004 Propellers, Remove, Inspect, and Reinstall (D) JOB 1 D-005 Rudder Assemblies, Remove, Inspect and Reinstall (D) JOB 1 D-006 Drydocking (D) JOB 1 D-007 Temporary Services, Provide (D) JOB 1 D-008 Sea Trial Performance, Support, Provide (D) JOB 1 O-009 Main Engine/Reduction Gear, Realign (O) JOB 1 O-010 Intermediate Water-Lubricated Propulsion Shaft Bearing, Renew (O) JOB 1 O-011 Aft Water-Lubricated Propulsion Shaft Bearing, Renew (O) JOB 1 O-012 Intermediate Bearing Carrier, Renew (O) JOB 1 O-013 Stern Tubes, Interior Surfaces, Repair (O) JOB 1 D-014 Cathodic Protection/Zinc Anodes, Renew (D) JOB 1 O-015 Aft Bearing Carrier, Renew (O) JOB 1 O-A Composite Labor Rate` Hour 110 D-B GFP Report NSP EA 1 NSP O-Z Laydays` Day 5 Total Price of Definite Items Total Price of Optional Items Total Price of Definite and Optional Items Inspection and Acceptance is at destination CONTRACT CLAUSES (1) FAR CLAUSE 52.212-4 CONTRACT TERMS AND CONDITIONS ---COMMERCIAL ITEMS (SEP 2013) (a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights -- (1) Within a reasonable time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C.3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to the Contract Disputes Act of 1978, as amended (41 U.S.C. 601-613). Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include -- (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, contract line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer- System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment. (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR Part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall- (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the- (A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected contract line item or subline item, if applicable; and (D) Contractor point of contact. (ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer. (6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in Section 611 of the Contract Disputes Act of 1978 (Public Law 95-563), which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period at fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract. (iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if- (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days; (B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or (C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates: (A) The date fixed under this contract. (B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on- (A) The date on which the designated office receives payment from the Contractor; (B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or (C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor. (vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or (2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination. (k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. 3701, et seq., Contract Work Hours and Safety Standards Act; 41 U.S.C. 51-58, Anti-Kickback Act of 1986; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. 423 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) The schedule of supplies/services. (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause. (3) The clause at 52.212-5. (4) Addenda to this solicitation or contract, including any license agreements for computer software. (5) Solicitation provisions if this is a solicitation. (6) Other paragraphs of this clause. (7) The Standard Form 1449. (8) Other documents, exhibits, and attachments. (9) The specification. (t) System for Award Management (SAM). (1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (2) (i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to: (A) Change the name in the SAM database; (B) Comply with the requirements of Subpart 42.12 of the FAR; (C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract. (3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov. (u) Unauthorized Obligations. (1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End Use License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (i) Any such clause is unenforceable against the Government. (ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an "I agree" click box or other comparable mechanism (e.g., "click-wrap" or "browse-wrap" agreements), execution does not bind the Government or any Government authorized end user to such clause. (iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. (End of Clause) ADDENDUM to FAR CLAUSE 52.212-4: the following paragraphs are added to the clause: (2) FAR 52.217-7 OPTION FOR INCREASED QUANTITY - SEPARATELY PRICED LINE ITEM (MAR 1989) - VARIATION The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of essence, initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options maybe exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired. (3) 52.232-40 - PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (Dec 2013) As prescribed in 32.009-2, insert the following clause: (a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor. (b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act. (c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items. (End of clause) (4) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html FAR 52.211-14 Notice of Priority Rating For National Defense EMERGENCY Preparedness, and Energy Program Use (DO) (APR 2008) FAR 52.211-15 Defense Priority and Allocation Requirements (APR 2008) DO-N5 Rating FAR 52.215-5 Facsimile Proposals. (OCT 1997) FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) FAR 52.228-5 Insurance - Work on a Government Installation (JAN 1997) FAR 52.232-18 Availability of Funds (APR 1984) FAR 52.242-2 Production Progress Reports (APR 1991) FAR 52.245-1 Government Property (APR 2012) FAR 52.245-9 Use and Charges (APR 2012) FAR 52.249-1 Termination for Convenience of the Government (Fixed Price) ( APR 1984) short form HSAR 3052.205-70 Advertisements, Publizing Awards, and Releases (SEP 2012) HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-90 Delivery and Shifting of Vessel (DEC 2003) HSAR 3052.217-91 Performance (DEC 2003) HSAR 3052.217-92 Inspection and Manner of Doing Work (DEC 2003) HSAR 3052.217-93 Subcontracts (DEC 2003) HSAR 3052.217-94 Lay Days (DEC 2003) HSAR 3052.217-95 Liability and Insurance (DEC 2003) HSAR 3052.217-96 Title (DEC 2003) HSAR 3052.217-97 Discharge of liens (DEC 2003) HSAR 3052.217-98 Delays (DEC 2003) HSAR 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair (DEC 2003) HSAR 3052.217-100 Guarantee (JUN 2006) HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.242-72 Contracting Officer's Technical Representative (DEC 2003) is the COR (5) HSAR 3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUNE 2006) (a) Prohibitions. Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security. (b) Definitions. As used in this clause: Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears. Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986. Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)- (1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership; (2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held- (i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or (ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership; and (3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group. Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and (5) of section 7701(a) of the Internal Revenue Code of 1986, respectively. (c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation. (1) Certain stock disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership: (i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or (ii) Stock of such entity which is sold in a public offering related to an acquisition described in section 835(b)(1) of the Homeland Security Act, 6 U.S.C. 395(b)(1). (2) Plan deemed in certain cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan. (3) Certain transfers disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section. (d) Special rule for related partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C. 395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership. (e) Treatment of Certain Rights. (1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows: (i) warrants; (ii) options; (iii) contracts to acquire stock; (iv) convertible debt instruments; and (v) others similar interests. (2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835. (f) Disclosure. The offeror under this solicitation represents that [Check one]: __ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003; __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it has submitted a request for waiver pursuant to 3009.108-7004, which has not been denied; or __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it plans to submit a request for waiver pursuant to 3009.108-7004. (g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if a waiver has been applied for, shall be attached to the bid or proposal. (6) HSAR 3052.223-70 REMOVAL OR DISPOSAL OF HAZARDOUS SUBSTANCES - APPLICABLE LICENSES AND PERMITS (JUN 2006) The Contractor shall have all licenses and permits required by Federal, state, and local laws to perform hazardous substance(s) removal or disposal services. If the Contractor does not currently possess these documents, it shall obtain all requisite licenses and permits within ten (10) days after date of award. The Contractor shall provide evidence of said documents to the Contracting Officer or designated Government representative prior to commencement of work under the contract. (End of clause) (7) HAZARDOUS WASTE Contractors performing dockside ship repair work at Government facilities are required to comply with FAR 52.223-3, Hazardous Material Identification and Material Safety Data (JAN 1997) Alt I, the U.S. Coast Guard shipboard hazardous waste policy, as prescribed in COMDINST M16478.1B, and MLCA standard specifications. Disposal of all hazardous wastes shall be performed by the Contractor and the Contractor shall meet all federal and state requirements. The Contractor is also required to submit an acceptable hazardous waste management plan to the Port Engineer at the Arrival Conference. The plan will be reviewed by the facility hazardous waste manager. An acceptable plan must address, at a minimum, the following requirements: (a) EPA and local authority hazardous waste generator ID numbers or registration of the Contractors, his transporters, and disposal facilities (TSDFs); (b) An inventory of all hazardous chemicals, compounds and other agents brought aboard the facility accompanied by their respective Material Safety Data Sheets; (c) A list of all anticipated hazardous wastes to be generated and a federal/state/local regulation cross reference list for those wastes; (d) Waste collection and containment procedures; (e) A hazardous material spill and cleanup plan including tools and materials that will be on hand and readily available to facility containment and cleanup; (f) Training certification for the Contractor's hazardous waste manager. (8) VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS (a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state's "State Implementation Plan" (SIP) and the type/quantity of the Contractor's regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions. (b) Contractors, therefore, must submit the following to the designated Port Engineer not later than two weeks after contract award: 1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor's facility or offsite work places; 2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor's facility or offsite work places. (c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor's facility or offsite workplaces, then Contractor shall submit to the designated Port Engineer a letter, notarized under oath, that such documents are not required. (d) Contractors will submit the following to the designated Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with MLCA Standard Spec 63000N, Section 5.3.1. (9) TELEPHONE CHARGE The Commanding Officer of the Cutter will pay all toll charges and applicable taxes and surcharges for long-distance telephone calls placed by ship's personnel. All other charges shall be borne by the Contractor. (10) ACCESSIBILITY OF CONTRACTOR'S FACILITY The Contractor shall provide a facility accessible from a navigable waterway at which a ship of the characteristics described in the attached specification can, using its own propulsion, safely arrive, lie afloat and depart at all states of the tide and at any time day or night. The facility and its approaches shall have a minimum water depth of 12 feet and a minimum vertical clearance of 60 feet. (11) REQUIRED INSURANCE The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including: 1. Ship Repairer's Liability - $500,000 per occurrence. 2. Comprehensive General Liability - $500,000 per occurrence. 3. Full insurance coverage in accordance with the United States' Longshoremen's and Harbor Worker's Act. 4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract. The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured. (12) ACCESS TO VESSEL (a) A reasonable number of officers, employees, and associates of the Government, or other Prime Contractors with the Government, and their subContractors, shall, as authorized by the Contracting Officer, have, at all reasonable times, admission to the plant, and access to vessel(s) to perform and fulfill their respective obligations to the Government on a noninterference basis. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Contracting Officer, to be given admission to the Contractor's facilities and access to the vessel(s) and to office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of their respective responsibilities and reasonable to their performance. All such above personnel shall be required to comply with all Contractor rules and regulations governing personnel at its shipyard, including those relative to safety and security. (b) The Contractor further agrees, as authorized by the Contracting Officer, to afford to a reasonable number of officers, employees, and associates of bidders on other contemplated work, the same privileges of admission to the Contractor's plant and access to the vessel(s) on a noninterference basis subject to all Contractor rules and regulations governing personnel in its shipyard, including those relative to safety and security. (13) INDEMNIFICATION FOR ACCESS TO VESSELS Notwithstanding any provision in the "Access to Vessels" clause, or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other Prime Contractors with the Government and their subContractors, and officers, employees, and associates of quoters on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price. (14) INSPECTIONS Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract. The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation. (15) GROWTH WORK (a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated. (b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any Quotation submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the Quotation includes a request for a time extension, justification shall be furnished with the Quotation. (c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor and shall be included in the Composite Labor Rate. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC. (16) DISCOVERIES AND CHANGES TO CONTRACT Work requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during an availability: Work Request Process will occur in the following order: 1. Condition Found Report-Generated by the contractor and provided to COR 2. Condition Report Reply-Generated by the COR and provided to Contractor 3. Work Request- WR and IGE are generated by the COR and forwarded to KO 4. COR provides copy of Work Request to the Contractor 5. Contractor's Quotation- Provided to the KO for the identified tasking on WR 6. Negotiations- If needed, take place to establish pricing 7. Approved Work Request- Forwarded to Contractor and COR by the KO 8. Modification to Contract- The KS/KO will issue a modification covering all WR's (17) COMPOSITE LABOR RATE The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract. (a) The composite labor hour rate shall represent total compensation for the following: (1) direct labor wages and salaries; (2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits; (3) other direct costs associated with transit time, delay, disruption, consumables, expendable supplies, and equipment; (4) all indirect costs such as overhead and general and administrative expense; (5) any port or association fees, rents, or other levies; (6) profit (fee); (7) all direct and indirect costs and profit associated with the following support functions: Supervision and Management Planning and Estimating Material Handling Housekeeping Engineering Transportation/Drivers Quality Assurance Contract Administration Security Testing (8) all consumables; (b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated. (c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government's best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised. (18) MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT 1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed. 2. The items listed in the specification, as government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all government furnished property using either a DD Form 1149, entitled, "Requisition and Invoice/Shipping Document" or a DD Form 1348, entitled, "Issue Release/Receipt Document". A copy of the DD 1149 or DD 1348 must be sent within 48 hours of receipt of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator. 3. The Contractor shall complete the report provided herein, entitled, "Government Property Report". This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1 (a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator. 4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of government property to the Coast Guard. This includes government property taken off the vessel (shafts, propellers, etc.), government property returned to the vessel (special tools, etc.) or surplus government property not used during performance of the contract. (19) CONTRACTING OFFICER'S AUTHORITY No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof. (20) CONTRACTOR PERFORMANCE EVALUATION The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror's past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award. (b) NOTIFICATION: Upon completion of the contract, the contractor will be notified of the assessment. The contractor will be allowed 30 days to respond to the SFLC's assessment of its performance entered into CPARS. The contractor's response, if any, will be made part of the CPAR system at https://www.cpars.csd.disa.mil. (c) INFORMATION: Information included in the CPAR may include, but is not limited to, the contractor's record of conforming to contract requirements and to standards of good workmanship; the contractor's record of forecasting and controlling costs; the contractor's adherence to contract schedules, including the administrative aspects of performance; the contractor's history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor's record of integrity and business ethics, and generally, the contractor's business-like concern for the interest of the customer. (d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the contractor. (21) METHOD OF PAYMENT AND INVOICING INSTRUCTIONS INVOICE SUBMISSION PROCESS 1. The Contractor shall prepare a proper invoice IAW FAR clause 52.212-4, and in addition to the information required by FAR 52.212-4(g) as cited in the contract. All invoices shall be itemized to correlate to the Schedule of Supplies/Services. Invoices should be submitted for payment directly to the finance center upon completion of the contract. All information must be included in an invoice for it to constitute a proper invoice. All improper invoices will be rejected which could delay payment. 2. Visit the U.S. Coast Guard Finance Center Website for instructions regarding electronic submission of invoices: http://www.fincen.uscg.mil/electron_cg23.htm. 3. A copy of the invoice and any supporting documentation shall also be e-mailed to the following individuals: William.J.Veilleux@uscg.mil Jaime.R.Smith@uscg.mil Additional work verbally agreed to by the parties that has not yet been incorporated into the contract by modification shall not be included in an invoice. Payments will not be made for any work to which a modification has not been properly executed. Invoices submitted for payment that includes such a request will be reduced by the unmodified amount NOTE: 10% OF THE TOTAL CONTRACT PRICE WILL BE WITHHELD UNTIL ALL DELIVERABLES, REQUIRED BY THE CONTRACT, ARE RECEIVED AND ACCEPTED. FURTHER CONSIDERATIONS WITH INVOICING: In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received: (1) On the later of: (i) For invoices that are mailed the date a proper invoice is actually received by the designated billing office and annotates the invoice with date of receipt at the time of receipt. (ii) For invoices electronically transmitted by the contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or (ii) The seventh day after the date on which the property is actually delivered or performance of the services is actually completed; unless- a) The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or b) A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date; (2) On the date placed on the invoice by the contractor, when the agency fails to annotate the invoice with date of receipt of the invoice at the time of receipt (such invoice must be a proper invoice); or (3) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice. (4) Web based submission by the contractor and receipt confirmation does not reflect government review or acceptance of the invoice. (5) For inquiries and payment status please visit https://fincen.uscg.mil/secure/payment.htm The Data Universal Numbering System (DUNS) number is the primary identifier in Central Contractor Registration (CCR), (see FAR 52.232-33, Payment by Electronic Funds Transfer - Central Contractor Registration (OCT 2003)). Contractors are located and identified in CCR by their DUNS number. Therefore, to facilitate payment, the DUNS number shall be recorded on every invoice submitted to the U.S. Coast Guard. All payments for partial performance rendered by the Government under this contract are based on the assumption that the Contractor will, in good faith, execute and honor all payment terms entered into between it, the Prime Contractor, and any subcontractor thereof in the performance of this contract. The Contractor hereby acknowledges the Government's right to reduce or suspend progress payments based on non-payment in accordance with any payment terms of the subcontract agreement. Any amount deemed not payable will be deducted from the Contractor's invoice. Deducted amounts may be resubmitted on the next invoice for reconsideration. (22) CONTRACT DEFICIENCY REPORT The Contracting Officer or Contracting Officer's Representative (COR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COR in writing. (End of FAR 52.212-4 Addendum) (23) FAR CLAUSE 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (JAN 2014) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). ____ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)). (2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] _X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). _X_ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) 52.204-11, American Recovery and Reinvestment Act-Reporting Requirements (Jul 2010) (Pub. L. 111-5). ___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). ___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). _X_ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (31 U.S.C. 6101 note). _X_ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). ___ (10) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (May 2012) (section 738 of Division C of Public Law 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L. 110-161). ___ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (13) [Reserved] _X_ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. _X_ (16) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)). ___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Jul 2013) (15 U.S.C. 637 (d)(4)). ___ (ii) Alternate I (Oct 2001) of 52.219-9. ___ (iii) Alternate II (Oct 2001) of 52.219-9. ___ (iv) Alternate III (July 2010) of 52.219-9. ___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). ___ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). ___ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (21) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer). ___ (ii) Alternate I (June 2003) of 52.219-23. ___ (22) 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting (Jul 2013) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (23) 52.219-26, Small Disadvantaged Business Participation Program-Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (24) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). ___ (25) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). ___ (26) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013) (15 U.S.C. 637(m)). ___ (27) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)). _X_ (28) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (29) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126). _X_ (30) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _X_ (31) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). _X_ (32) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). _X_ (33) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). _X_ (34) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212). _X_ (35) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X_ (36) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ___ (39) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423). ___ (ii) Alternate I (Dec 2007) of 52.223-16. _X_ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011). _X_ (41) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d). ___ (42) (i) 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act (Nov 2012) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, Pub. L. 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). ___ (ii) Alternate I (Mar 2012) of 52.225-3. ___ (iii) Alternate II (Mar 2012) of 52.225-3. ___ (iv) Alternate III (Nov 2012) of 52.225-3. ___ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X_ (44) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2303 Note). ___ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). ___ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). _X_ (50) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (51) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (52) 52.232-36, Payment by Third Party (Jul 2013) (31 U.S.C. 3332). ___ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (54) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). ___ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.). ___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.). ___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). ___ (7) 52.222-17, Nondisplacement of Qualified Workers (Jan 2013) (E.O. 13495). ___ (8) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). ___ (9) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (ii) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) 52.222-17, Nondisplacement of Qualified Workers (Jan 2013) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). (vi) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (viii) 52.222-41, Service Contract Act of 1965, (Nov 2007), (41 U.S.C. 351, et seq.) (ix) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.) (xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.) (xii) 52.222-54, Employment Eligibility Verification (Aug 2013). (xiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xv) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) SOLICITATION PROVISIONS (24) FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at: http://www.arnet.gov/index.html. (25) FAR PROVISION 52.212-1 INSTRUCTIONS TO OFFEROR'S-COMMERCIAL ITEMS (JUL 2013); is hereby incorporated by reference in accordance with FAR 52.252-1. ADDENDUM to FAR PROVISION 52.212-1: the following paragraphs are added to the provision: (26) FAR PROVISION 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS ITEMS (JUN 1988) a. Orders for U.S. Coast Guard specification reference drawings must be placed within 10 days of the solicitation issue date. To request drawings, contact the Contract Specialist listed herein. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.). Drawing measurements should be verified by the Contractor prior to ordering materials. (27) FAR PROVISION 52.215-20 REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING DATA (OCT 2010) ALT IV (OCT 2010) (a) Submission of cost or pricing data is not required (b) If the contracting officer cannot determine price reasonableness either in the initial solicitation or in any change to the contract after award, the contracting officer will require submission information in sufficient detail in order to make such determination. The information may be as follows: REQUEST FOR INFORMAL COST BREAKDOWN In addition to placing your offer in the appropriate place in Schedule of supplies and Prices, it is requested that you provide a breakdown of your costs, to include but not be limited to, those items identified in the sample format below: Trade, (i.e. laborers, rigger, etc.) Breakdown of labor grades by trade category Manhours per trade, per labor grade Cost/hour/trade Supplies/materials (description & cost of each) Sub-total Pension Plans Overhead at a rate of ______% Profit at a rate of ________% Total for item _____________ (28) FAR PROVISION 52.217-5 EVALUATION OF OPTIONS (JULY 1990) Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s). (29) FAR PROVISION 52.237-1 SITE VISIT (APR 1984) The Request for Quotation (RFQ) is for the dock side repairs of the USCGC BARRACUDA hereinafter referred to as "vessel". The vessel's temporary homeport is 1 Yerba Buena Road, San Francisco, CA 94130. The point of contact for site surveys is MKC Shane Nicholas or BMCS Chad Lynch, they can be reached at 707 444-0471. The Contract Specialist is Jaime Smith, who can be reached at 757 628-4646. (End of FAR 52.212-1 Addendum) (30) FAR PROVISION 52.212-2 EVALUATION - COMMERCIAL ITEMS (JAN 1999) QUOTES SHALL BE EVALUATED USING THE FOLLOWING CRITERIA: (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: FACTOR 1 - PAST PERFORMANCE: The offeror shall identify at least two (2) but no more than three (3) relevant (construction, overhaul, repair and alteration of ships) and current federal, state or local government or private contracts performed during the last three (3) years. For each contract, list: (a) Contract number and customer point of contact (including two (2) points of contact with telephone numbers) (b) Dollar value of the contract (Original and Final) (c) Type of service performed and whether Prime or subcontractor (d) Required completion date for the contract (e) Date the services were actually completed (f) Ship Name, Hull Number (g) Contract type (FFP, IDIQ, Requirement, Cost Type) (h) Percentage of growth in contract price (Additional work divided by award price) If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor. The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a)(2) Past Performance Evaluation. The Contractor's past performance will be evaluated according to the following factors and questions: Quality of Product or Service Did the customer get what was specified? Did the customer consider the final product high in quality? If warranty issues arose, were they promptly corrected? Schedule Was the contract completed on time? If not, reason why not (growth work, Contractor delayed, government delayed?) Business Relations How was the customer service? Was the Contractor committed to customer satisfaction? Would you use this company again (Why/Why not)? Management of Key Personnel Were subcontracts involved? Comments? In evaluating Contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Assessment Reports and other existing past performance ratings on relevant contracts. General trends in a Contractor's performance will also be considered. A quote without a record of relevant, past performance will not be evaluated favorably or unfavorably on past performance. FACTOR 2 - PRICE: Offeror's price shall represent the best and final price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness. **** Past Performance is more important than Price**** Award may be made without any type of discussions or negotiations. This is based on the Contracting Officer's determination after an evaluation has been completed on all offers. (31) FAR PROVISION 52.212-3 - OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEM (NOV 2013). An offeror shall complete only paragraph (b) of this provision if the offeror has completed the annual representations and certifications electronically via http://www.acquisition.gov. If an offeror has not completed the annual representations and certifications electronically at the System for Award Management (SAM) website, the offeror shall complete only paragraphs (c) through (o) of this provision. (a) Definitions. As used in this provision- "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Forced or indentured child labor" means all work or service- (1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Inverted domestic corporation", as used in this section, means a foreign incorporated entity which is treated as an inverted domestic corporation under 6 U.S.C. 395(b), i.e., a corporation that used to be incorporated in the United States, or used to be a partnership in the United States, but now is incorporated in a foreign country, or is a subsidiary whose parent corporation is incorporated in a foreign country, that meets the criteria specified in 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). An inverted domestic corporation as herein defined does not meet the definition of an inverted domestic corporation as defined by the Internal Revenue Code at 26 U.S.C. 7874. "Manufactured end product" means any end product in Federal Supply Classes (FSC) 1000-9999, except- (1) FSC 5510, Lumber and Related Basic Wood Materials; (2) Federal Supply Group (FSG) 87, Agricultural Supplies; (3) FSG 88, Live Animals; (4) FSG 89, Food and Related Consumables; (5) FSC 9410, Crude Grades of Plant Materials; (6) FSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) FSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) FSC 9610, Ores; (9) FSC 9620, Minerals, Natural and Synthetic; and (10) FSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate- (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. "Sensitive technology"- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). "Service-disabled veteran-owned small business concern"- (1) Means a small business concern- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. "Subsidiary" means an entity in which more than 50 percent of the entity is owned- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. "Veteran-owned small business concern" means a small business concern- (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. "Women-owned small business concern" means a small business concern- (1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program" (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. (b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________. [Offeror to identify the applicable paragraphs at (c) through (o) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.] (c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it [ ] is, [ ] is not a small business concern. (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern. (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, for general statistical purposes, that it [ ] is, [ ] is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ] is, [ ] is not a women-owned small business concern. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that- (i) It [ ] is, [ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that- (i) It [ ] is, [ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it o is a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:____________________________________ (10) [Complete only if the solicitation contains the clause at FAR 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns, or FAR 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting, and the offeror desires a benefit based on its disadvantaged status.] (i) General. The offeror represents that either- (A) It [ ] is, [ ] is not certified by the Small Business Administration as a small disadvantaged business concern and identified, on the date of this representation, as a certified small disadvantaged business concern in the SAM Dynamic Small Business Search database maintained by the Small Business Administration, and that no material change in disadvantaged ownership and control has occurred since its certification, and, where the concern is owned by one or more individuals claiming disadvantaged status, the net worth of each individual upon whom the certification is based does not exceed $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); or (B) It [ ] has, [ ] has not submitted a completed application to the Small Business Administration or a Private Certifier to be certified as a small disadvantaged business concern in accordance with 13 CFR 124, Subpart B, and a decision on that application is pending, and that no material change in disadvantaged ownership and control has occurred since its application was submitted. (ii) [ ] Joint Ventures under the Price Evaluation Adjustment for Small Disadvantaged Business Concerns. The offeror represents, as part of its offer, that it is a joint venture that complies with the requirements in 13 CFR 124.1002(f) and that the representation in paragraph (c)(10)(i) of this provision is accurate for the small disadvantaged business concern that is participating in the joint venture. [The offeror shall enter the name of the small disadvantaged business concern that is participating in the joint venture: ________________.] (11) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that- (i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and (ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(11)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Representations required to implement provisions of Executive Order 11246- (1) Previous contracts and compliance. The offeror represents that- (i) It [ ] has, [ ] has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and (ii) It [ ] has, [ ] has not filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that- (i) It [ ] has developed and has on file, [ ] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 cfr parts 60-1 and 60-2), or (ii) It [ ] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Act Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American Act-Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item" "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American Act-Supplies." (2) Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g)(1) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American Act-Free Trade Agreements-Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms "Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product," "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," "Free Trade Agreement country," "Free Trade Agreement country end product," "Israeli end product," and "United States" are defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act." (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." Other Foreign End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act": Canadian End Products: Line Item No. _______________________________________ _______________________________________ _______________________________________ [List as necessary] (3) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act": Canadian or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (4) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American Act-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled "Trade Agreements." (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products: Line Item No. Country of Origin ______________ _________________ ______________ _________________ ______________ _________________ [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American Act. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals- (1) [ ] Are, [ ] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) [ ] Have, [ ] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; (3) [ ] Are, [ ] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) [ ] Have, [ ] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at 22.1503(b).] (1) Listed end products. Listed End Product Listed Countries of Origin ___________________ ___________________ ___________________ ___________________ (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] [ ] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. [ ] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) [ ] In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) [ ] Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Act. (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.] [ ] (1) Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror [ ] does [ ] does not certify that- (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. [ ] (2) Certain services as described in FAR 22.1003-4(d)(1). The offeror o does o does not certify that- (i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies- (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Act wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer Identification Number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN. (3) Taxpayer Identification Number (TIN). [ ] TIN: ________________________________. [ ] TIN has been applied for. [ ] TIN is not required because: [ ] Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; [ ] Offeror is an agency or instrumentality of a foreign government; [ ] Offeror is an agency or instrumentality of the Federal Government. (4) Type of organization. [ ] Sole proprietorship; [ ] Partnership; [ ] Corporate entity (not tax-exempt); [ ] Corporate entity (tax-exempt); [ ] Government entity (Federal, State, or local); [ ] Foreign government; [ ] International organization per 26 CFR 1.6049-4; [ ] Other ________________________________. (5) Common parent. [ ] Offeror is not owned or controlled by a common parent; [ ] Name and TIN of common parent: Name ________________________________. TIN _________________________________. (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations. (1) Relation to Internal Revenue Code. An inverted domestic corporation as herein defined does not meet the definition of an inverted domestic corporation as defined by the Internal Revenue Code 25 U.S.C. 7874. (2) Representation. By submission of its offer, the offeror represents that- (i) It is not an inverted domestic corporation; and (ii) It is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall e-mail questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation and Certifications. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror- (i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and (iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,000 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf). (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if- (i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products.
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/USCG/COUSCGMLCA/HSCG80-14-Q-P45H77/listing.html)
Place of Performance: Address: Per US Coast Guard Area Instruction 3100.1F, the vessel is restricted to the California (San Francisco Bay and South) Home port CPBs: United States West Coast San Francisco Bay and South for dry dock repairs. No contract shall be awarded to a facility located outside of this geographic restriction., San Francisco, California, United States
Record: SN03344507-W 20140423/140421235000-3522bdfdd7330328c5ec3485dd2abb41 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

20 -- Emergency Drydock Repairs CGC Barracuda - SF1449