SOLICITATION NOTICE
Z -- Cooling Tower Replacement
- Notice Date
- 3/4/2014
- Notice Type
- Presolicitation
- NAICS
- 238220
— Plumbing, Heating, and Air-Conditioning Contractors
- Contracting Office
- General Services Administration, Public Buildings Service (PBS), Property Management Division (4PM)*, 401 West Peachtree Street, Suite 2416, Atlanta, Georgia, 30308
- ZIP Code
- 30308
- Solicitation Number
- GS-04P-14-EX-C-0050
- Archive Date
- 5/16/2014
- Point of Contact
- Dee O Henderson, Phone: 404-331-9792
- E-Mail Address
-
dee.henderson@gsa.gov
(dee.henderson@gsa.gov)
- Small Business Set-Aside
- Total Small Business
- Description
- COOLING TOWER REPLACEMENT This project will be a 100% Small Business Set-Aside. The NAICS code is 238220. Project location is Cookeville US Post Office and Courthouse, 9E Broad Street, Cookeville, TN 38503. The Contractor shall provide material, labor, equipment, and supervision to conduct the following work: Furnish and Install 60 ton cooling tower, dispose of existing tower, placement and balancing of new tower, new pad, modificaton of steel enclosure, tie in insulated piping to feed the new tower, replacement of controls box and controls wiring, connect existing tower drain line to sewer per code: The Contractor should visit the site prior to bidding on this project in order to verify all dimensions and familiarize him/herself with the existing conditions, so that they may obtain a full knowledge of any and all difficulties that may be encountered in execution of the work. The Contracting Officer is Dee Otis Henderson, 404-331-9792. The Project Manager is Johnathan Sitzlar, 865-545-4330. Work shall be performed in accordance with all applicable State and Federal codes, and shall be done by a Specialty Contractor skilled in the trade. All work shall be completed within 60 days after Contractor's receipt of contract award. If conditions prevent completion within the schedule, the Contractor shall request a time extension in writing, giving specific reasons why an extension should be granted. The Construction Magnitude is $25,000 to $100,000. The liquidated damages are $844.37 per day.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/GSA/PBS/4PMAtlanta/GS-04P-14-EX-C-0050/listing.html)
- Place of Performance
- Address: Cookeville US Post Office and Courthouse, 9E Broad Street, Cookeville, TN 38503, Cookeville, Tennessee, 38503, United States
- Zip Code: 38503
- Zip Code: 38503
- Record
- SN03301396-W 20140306/140304235044-a336bddb1fd08a409410941f93fa2078 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |