Loren Data's SAM Daily™

FBO DAILY - FEDBIZOPPS ISSUE OF MARCH 02, 2014 FBO #4481
SOLICITATION NOTICE

20 -- UNPLANNED DRY-DOCK REPAIRS USCGC SCIOTO BARGE (99002) AND DOCKSIDE REPAIRS USCGC SCIOTO TENDER (WLR-65504) FY14 - Specification

Notice Date

2/28/2014
 

Notice Type

Combined Synopsis/Solicitation
 

NAICS

336611 — Ship Building and Repairing
 

Contracting Office

Department of Homeland Security, United States Coast Guard (USCG), USCG Surface Forces Logistics Center (SFLC) Procurement Branch 2, 1301 Clay St., Suite 807N, Oakland, California, 94612-5249, United States
 

ZIP Code

94612-5249
 

Solicitation Number

HSCG85-14-Q-P45B41
 

Archive Date

3/29/2014
 

Point of Contact

Jack Rodman, Phone: (510) 637-5988, Jay S McReynolds, Phone: 510-637-5975
 

E-Mail Address

Jack.E.Rodman@uscg.mil, jay.s.mcreynolds@uscg.mil
(Jack.E.Rodman@uscg.mil, jay.s.mcreynolds@uscg.mil)
 

Small Business Set-Aside

Total Small Business
 

Description

GFE Form Pricing Sheet Specification This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice, and FAR Subpart 13.5, Test Program for Certain Commercial Items. This solicitation is for an Unplanned Dry Dock Repairs for the United States Coast Guard Cutter: SCIOTO (WLR-65504) Dockside Repairs and Dry-Dock Repairs for the SCIOTIO'S Barge (99002). The BARGE is a 100 Foot Construction Barge. The minimum depth is 6 feet the maximum beam is 30 feet 7 inches, the full load draft is 4 feet, and the full load displacement is 237 Short tons. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued. Solicitation number HSCG85-14-Q-P45B41 is issued as a Request for Quotations (RFQ). HSCG85-14-Q-P45B41 and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 05-46. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 12. The Small Business Size Standard for NAICS Code 336611 is 1000 employees. A Firm-Fixed Price Contract for the base items is anticipated. The anticipated award date is on or about March 21, 2014. Work covered by this solicitation shall be completed within (29) calendar days from the date the vessel becomes available to the contractor. The availability is scheduled to start on or about March 26, 2014 and end on April 23, 2014 The Place of Performance will be at the contractor's facility. The Cutter's home port is: 221 Mississippi Dr, Keokuk IA, 52002. For Cutter and Barge access, please contact MKC Michael Koblas at (321) 536-7526 or LTJG Samuel Merritt at (617) 833-3034. The government intends to award from this solicitation to the responsible vendor whose quote conforming to the solicitation provides the best value. GEOGRAPHIC RESTRICTION: THE GEOGRAPHIC RESTRICTION IS 600 RIVER STATUE MAILES ONE-WAY 1200 ROUND TRIP. THIS IS A ONE TIME RESTIRCTION. REFERENCE: MESSAGE R #202029Z FEB, 14, 2014 (See Attachments to this Synopsis/Solicitation): Pricing Schedule Work Specification Government Property Form NOTICE FOR FILING AGENCY PROTESTS United States Coast Guard Ombudsman Program It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman. Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable). Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester's concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to: COMMANDANT (CG-9131) U S COAST GUARD OMBUDSMAN PROGRAM FOR AGENCY PROTESTS 2100 2ND ST SW STOP 7112 WASHINGTON DC 20593-7112 The Ombudsman Hotline telephone number is 202.372.3695. DESCRIPTION OF WORK A. This work item describes the requirements for the Contractor to drydock and undock the barge and perform various dry-docking-related tasks. B. This work item describes the requirements for the Contractor to perform Dockside Repairs on the Tender. CERTIFICATIONS (a) All welding and brazing shall be accomplished by trained welders who have been certified by the applicable regulatory code performance qualification procedures. Must be provided with quotation. PLEASE NOTE: QUOTES MUST INCLUDE ALL DOCUMENTS REQUESTED IN THIS SOLICITATION (DRYDOCK CERTIFICATION (USCG), WELDING CERTIFICATES,PRE-DOCKING CALULATIONS, PAST PERFORMANCE, ETC). QUOTES THAT DO NOT INCLUDE ALL DOCUMENTS REQUESTED MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED. GEOGRAPHIC RESTRICTION: THE GEOGRAPHIC RESTRICTION IS 600 RIVER STATUE MAILES ONE-WAY 1200 ROUND TRIP. THIS IS A ONE TIME RESTIRCTION. REFERENCE: MESSAGE R #202029Z FEB, 14, 2014 Each quoter shall furnish the information required by the solicitation. VESSEL HOME PORT: 1900 Coast Guard Road, Demopolis AL, 36732 PRICE TOTALS Insert individual prices in Schedule of Supplies/Services above and insert totals of extended prices as indicated below: Total Definitive Item CLINs: tiny_mce_marker________________ Total Optional Item CLINs: tiny_mce_marker________________ Excluding Composite Labor And Lay Days Composite Labor: tiny_mce_marker________________ Lay Days: tiny_mce_marker________________ TOTAL: tiny_mce_marker________________ PRICING DATA: Base Contract Line Item Numbers (CLINs) are marked as "D" for Definitive. Optional CLINS are marked "O" for Optional. Insert unit prices in all CLINs listed in the Schedule unless "NSP" is printed in the Unit Price column for any CLIN. "NSP" in the section means "Not Separately Priced." PRICING SCHEDULE FOR: USCGC SCIOTO (WLR-65B) UNPLANNED DRYDOCK AVAILABILITY FY2014 ITEM DESCRIPTION UNIT PRICE UNIT QTY EXTENDED PRICE O-001 Hull and Structural Plating (General) - 12.75-Pound Steel Plate, Repair - Barge (Optional) SQ FT 40 O-002 Hull and Structural Plating (General) - 15.3-Pound Steel Plate, Repair - Barge (Optional) SQ FT 40 D-003 Dry-docking - Barge DAY 28 D-004 Temporary Services, Provide DAY 28 D-005 Hull, Repair (Barge) JOB 1 D-006 Fresh Water Tank, Repair (Tender) JOB 1 O-007 Tank (MP Fuel Service), Clean and Inspect - Tender (Optional) JOB 1 D-008 Tank (MP Fuel Stowage and Overflow), Clean and Inspect - Barge JOB 1 O-00A Composite Labor Rate Hour 220 D-00B GFP Report NSP EA O-00Z Laydays Day 5 Total Price of Definite Items Total Price of Option Items Total Price of Definite and Optional Items Refer questions to Jack Rodman, Contract Specialist (510) 637-5988. Quotes must arrive no later than 10:00 am. Pacific Time, March 14, 2014. Quotations may be sent via electronic mail (e-mail) to Jack.E.Rodman@uscg.mil, the US Postal Service, or hand delivered to: USCG Surface Forces Logistics Center, Attn: Jack Rodman, 1301 Clay Street, Suite 807N, Oakland California 94612-5249. As per FAR 52.215-5 FACSIMILE PROPOSALS (OCT 1997), offerors may submit facsimile quotes as responses to this solicitation. E-mail and Facsimile proposals are subject to the same rules as paper proposals. The telephone number for receiving facsimiles is (510) 637-5877. No hard copies of this combined synopsis/solicitation will be issued. Inspection and Acceptance is at destination. CONTRACT CLAUSES (1) The provision at FAR 52.212-1, Instructions to Offerors - Commercial Items (July 2013) applies to this acquisition (with the exception of paragraph f). (2) FAR 52.212-2, Evaluation--Commercial Items (Jan 1999) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: The offeror shall identify at least two (2) relevant (construction, overhaul, repair and alteration of ships) federal, state or local government or private contracts performed during the last three (3) years. For each contract, list: a. Contract number and customer point of contact (including two (2) points of contact With telephone numbers) b. Dollar value of the contract (Original and Final) c. Type of service performed and whether Prime or subcontractor d. Required completion date for the contract e. Date the services were actually completed f. Ship Name, Hull Number g. Contract type (FFP, IDIQ, Requirement, Cost Type) h. Percentage of growth in contract price (Additional work divided by award price) If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor. PAST PERFORMANCE: The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a) (2) Past Performance Evaluation. The contractor's past performance will be evaluated according to the following factors and questions: - Quality of Product or Service Did the customer get what was specified? Did the customer consider the final product high in quality? If warranty issues arose, were they promptly corrected? - Timeliness of Performance Was the contract completed on time? If not, reason why not (growth work, contractor delayed, government delayed?) - Business Relations How was the customer service? Was the contractor committed to customer satisfaction? Would you use this company again (Why/Why not)? - Subcontracts Were subcontracts involved? Comments? In evaluating contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Reports and other existing past performance ratings on relevant contracts. General trends in a contractor's performance will also be considered. PRICE: The Total evaluated price of the offeror will be determined by totaling the proposed prices of all the Definite Items, plus the composite labor hour, lay days, and foreseeable costs.. a. Definite Items: These are items, which, if there is an award at all will be awarded. The proposal shall be evaluated to include the price for each definite item. b. Composite Labor Hour Rate: The offeror shall be evaluated to include the offer price for the Composite Labor Hour Rate multiplied by the estimated quantity of hours. c. Lay days: The offeror shall be evaluated to include the offer price for lay day rate multiplied by the estimated quantity of days. d. Foreseeable Costs: The offeror shall be evaluated to include the offer price and total foreseeable costs as delineated in the below paragraphs e. Offeror's price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness ****Past Performance is approximately equal Price**** FAR 52.215-6 PLACE OF PERFORMANCE (OCT 1997) (a) The offeror or respondent, in the performance of any contract resulting from this solicitation, [ ] intends, [ ] does not intend (check applicable block) to use one or more plants or facilities located at a different address from the address of the offeror or respondent as indicated in this request for quote. (b) If the offeror or respondent checks "intends" in paragraph (a) of this provision, it shall insert in the following spaces the required information: Place of Performance Name and Address of Owner and (Street Address, City, County, Operator of the Plant or Facility if Other State, Zip Code) than Offer or Respondent DISTANCE FACTOR ADJUSTMENT: (a) The work may be accomplished at the vessel's home pier or at the Contractor's Facility. If the Contractor is to perform the work at the Contractor's facility, the following distance adjustment factors will be applied to the prices quoted for this work. If the work is performed at the vessel's home pier, the following distance adjustment factors are not applicable. (b) If the work covered by this solicitation is performed elsewhere than the home pier of the vessel, the Coast Guard will incur certain costs incident to moving the vessel to and from such location. Furthermore, Coast Guard inspection and other support in connection with the work covered by this solicitation will be provided by SFLC Naval Engineering Support Unit (NESU) listed in the following paragraphs, which is responsible for support of the vessel. If work is performed elsewhere than at these SFLC locations, the Coast Guard will incur certain costs incident to providing inspection and other support. FORESEEABLE COST FACTORS PERTAINING TO DIFFERENT SHIPYARD LOCATIONS: (1) There will be a transportation cost for one U.S. Coast Guard Representative(s) for 4 round trip(s) between the Contractor's offered place of performance and NESU Boston, MA at the cost of coach-type airfare to be taken from the official airline guide or at a cost of $0.51 per mile if no airline service is available. (2) If the Contractor's offered place of performance is more than fifty (50) driving miles from NESU New Orleans, LA the "Per Diem" expenses for 16 days to support one U.S. Coast Guard Representative(s) while in the city of the place of contract performance will be determined in accordance with the Joint Federal Travel Regulations (JFTR). (3) Facility costs to navigate vessel between its home pier and the Contractor's offered place of performance (round trip) is $103.58 per Statue River mile. (4) Family separation allowance for 0 personnel with dependents on board at $8.33 per day for each personnel for 0 days each when the place of performance is more than fifty (50) driving miles from the home pier of the vessel. *The entitlement is calculated from the date the vessel leaves homeport and ends upon return to homeport. All travel dates will be included in this calculation. See U.S. Coast Guard Pay Manual, COMDTINST M7220.29, Chapter 3-F. (5) Crew's transportation during overhaul away from home port. As required by 37 USC 406 b. and Chapter 7, Part F1 of the Joint Federal Travel Regulations (JFTR), on the thirty-first (31) day of a ship being away from home port, and every sixty (60) days thereafter, all personnel with dependents will be provided round trip coach type airfare to the ship's home pier. There will be 0 home port visit(s) during the performance of this contract. The vessel has 0 personnel that will live on board. The cost of this airfare will be determined from the official airline guide. The calculation of trips does not include travel time to and from the overhaul place of performance. See Joint Federal Travel Regulations (JFTR), Chapter 5, Part C, paragraph U5222 and Chapter 7, Part F, paragraph U7115. (End of FAR 52.212-2) FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at: http://www.arnet.gov/index.html. FAR 217-5 EVALUATION OF OPTIONS (JUL 1990) FAR 52.211-14 -- NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008) Any contract awarded as a result of this solicitation will be [ ] DX rated order; [X] DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation. (End of Provision) DRYDOCK CERTIFICATION AND DRYDOCK CALCULATIONS: With his/her quote the Contractor shall provide a current certification of its dry-docking facility as required by the specification, Work Items D-003 Routine Dry-docking and SFLC Standard Specification 8634. When requested by the Contracting Officer, the Contractor shall also provide the pre-award calculations described in specification Work Items D-003, Routine Dry-docking, Barge Conditions, and Appendix A, B or C of the SFLC Standard Specification 8634. Subsequent to contract award, the Government will require the Contractor to provide the docking and un-docking calculations described in Appendix A, B or C of the SFLC Standard Specification 8634. FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS (JUN 1988) a. Orders for U.S. Coast Guard specification reference drawings must be placed BEFORE 03/06/2014. To request drawings, contact Jack.E.Rodman@uscg.mil. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.). Drawing measurements should be verified by the Contractor prior to ordering materials. FAR 52.216-1 TYPE OF CONTRACT (APR 1984) This Request for Quotes (RFQ) is issued in accordance with FAR Subpart 12 for Commercial Items. The Government contemplates award of a firm-fixed-price contract resulting from this solicitation. The offeror agrees to hold the prices in its offer firm for ninety (90) calendar days from the date specified for the receipt of offers. FAR 52.237-1 SITE VISIT (APR 1984): This RFQ is for the drydock repairs of the USCGC SCIOTO TENDER & BARGE (WLR-65504) &(99002) hereinafter referred to as "vessel" the vessel's home port is221 Mississippi Dr, Keokuk IA, 52002. The point of contact for Ship MKC Michael Koblas at (321) 536-7526 email:Michael.G.Koblas@uscg.mil or LTJG Samuel Merritt at (617) 833-3034 email Samuel.C.Merritt@uscg.mil. The Contracting Specialist is Jack Rodman who can be reached at 510-637-5988 or email Jack.E.Rodman@uscg.mil (End of Provision) FAR 52.215-20 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA OR INFORMATION OTHER THAN CERTIFIED COST OR PRICING DATA (OCT 2010) ALT IV (OCT 2010). (a) Submission of cost or pricing data is not required (b) If the contracting officer cannot determine price reasonableness either in the initial solicitation or in any change to the contract after award, the contracting officer will require submission information in sufficient detail in order to make such determination. The information may be as follows REQUEST FOR INFORMAL COST BREAKDOWN In addition to placing your offer in the appropriate place in Schedule of supplies and Prices, it is requested that you provide a breakdown of your costs, to include but not be limited to, those items identified in the sample format below: Trade, (i.e. laborers, rigger, etc.) Breakdown of labor grades by trade category Man-hours per trade, per labor grade Cost/hour/trade Supplies/materials (description & cost of each) Sub-total Pension Plans Overhead at a rate of ______% Profit at a rate of ________% Total for item _____________ FAR 52.212-3, Offeror Representations and Certifications - Commercial Items. (Nov 2013) applies to this acquisition. Offerors are required to submit, a completed copy of the provision at Offeror Representations and Certifications - Commercial Items, with their quote. An offeror shall complete only paragraph (j) of this provision if the offeror has completed the annual representations and certifications electronically at System For Award Management (SAM). To receive award contractor must be registered in System For Award Management (SAM) www.sam.gov/portal/public/SAM offeror shall complete only paragraphs (b) through (i) of this provision. (End of Provision) (4) FAR 52.212-4, Contract Terms and Conditions - Commercial Items (SEP 2013) and below addendum applies to this acquisition. (Addendum) FAR 52.217-7 OPTION FOR INCREASED QUANTITY - SEPARATELY PRICED LINE ITEM (MAR 1989) - VARIATION The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of the essence, initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired. (End of Clause) 52.232-18 -- Availability of Funds. Availability of Funds (Apr 1984) Funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer. 52.232-40 - Providing Accelerated Payments to Small Business (Dec 2013) (a) Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor. (b) The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act. (c) Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items. (End of Clause) FAR 52.246-4 -- Inspection of Services -- Fixed-Price (AUG 1996) (a) Definition: "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services. (b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires. (c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work. (d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. (e) If any of the services do not conform to contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by re-performance, the Government may -- (1) Require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and (2) Reduce the contract price to reflect the reduced value of the services performed. (f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may -- (1) By contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Government that is directly related to the performance of such service; or (2) Terminate the contract for default. (End of Clause) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html FAR 52.211-15 Defense Priority and Allocation Requirements (APR 2008) DO N5 Rating FAR 52.215-5 Facsimile Proposals (OCT 1997) FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) FAR 52.223-12 Refrigeration Equipment and Air Conditioners (MAY 1995) FAR 52.228-5 Insurance - Work on a Government Installation (JAN 1997) FAR 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) FAR 52.242-2 Production Progress Reports (APR 1991) FAR 52.245-1 Government Property (APR 2012) FAR 52.245-9 Use and Charges (APR 2012) HSAR 3052-205-70 Advertisement, Publicizing Awards, and Releases (Sept 2012) HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-90 Delivery and Shifting of Vessel (DEC 2003) HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-70 Removal or Disposal of Hazardous Substances - Applicable Licenses and Permits (JUN 2006) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.242-72 Contracting Officer's Technical Representative (DEC 2003) HSAR 3052.209-70 (PROHIBITION ON CONTRACTS WITH CORPORATE (EXPATRIATES) (JUN 2006) (a) Prohibitions. Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security. (b) Definitions. As used in this clause: Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for `at least 80 percent' each place it appears. Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986. Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)- (1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership; (2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held- (i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or (ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership; and (3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group. Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and (5) of section 7701(a) of the Internal Revenue Code of 1986, respectively. (c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation. (1) Certain stock disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership: (i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or (ii) Stock of such entity which is sold in a public offering related to an acquisition described in section 835(b)(1) of the Homeland Security Act, 6 U.S.C. 395(b)(1). (2) Plan deemed in certain cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan. (3) Certain transfers disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section. (d) Special rule for related partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C. 395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership. (e) Treatment of Certain Rights. (1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows: (i) warrants; (ii) options; (iii) contracts to acquire stock; (iv) convertible debt instruments; and (v) others similar interests. (2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835. (f) Disclosure. The offeror under this solicitation represents that [Check one]: __ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003; __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it has submitted a request for waiver pursuant to 3009.108-7004, which has not been denied; or __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.108-7001 through 3009.108-7003, but it plans to submit a request for waiver pursuant to 3009.108-7004. (g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if a waiver has been applied for, shall be attached to the bid or proposal. (End of clause) VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS: (a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state's "State Implementation Plan" (SIP) and the type/quantity of the Contractor's regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions. (b) Contractors, therefore, must submit the following to the designated NESU Port Engineer not later than two weeks after contract award: 1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor's facility or offsite work places; 2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor's facility or offsite work places. (c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor's facility or offsite workplaces, the Contractor shall submit to the designated NESU Port Engineer a letter, notarized under oath, that such documents are not required. (d) Contractors will submit the following to the designated NESU Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with SFLC Standard Spec 0000, Section B2.2.6. TELEPHONE CHARGE: The Commanding Officer of the Cutter will pay all toll charges and applicable taxes and surcharges for long-distance telephone calls placed by ship's personnel. All other charges shall be borne by the Contractor. REQUIRED INSURANCE: The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including: 1. Ship Repairer's Liability - $500,000 per occurrence. 2. Comprehensive General Liability - $500,000 per occurrence. 3. Full insurance coverage in accordance with the United States' Longshoremen's and Harbor Worker's Act. 4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract. The insurance certificate must provide the name of the US Coast Guard vessel and the contract number as specifically insured. ACCESS TO VESSEL: (a) A reasonable number of officers, employees, and associates of the Government, or other prime Contractors with the Government, and their subcontractors, shall, as authorized by the Contracting Officer, have, at all reasonable times, admission to the plant, and access to vessel(s) to perform and fulfill their respective obligations to the Government on a noninterference basis. Work hours for the vessel will be discussed at the Arrival Conference. Any work performed outside of those hours will be allowed at the sole discretion of the Contracting Officer. The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Contracting Officer, to be given admission to the Contractor's facilities and access to the vessel(s) and to office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of their respective responsibilities and reasonable to their performance. All such above personnel shall be required to comply with all Contractor rules and regulations governing personnel at its shipyard, including those relative to safety and security. (b) The Contractor further agrees, as authorized by the Contracting Officer, to afford to a reasonable number of officers, employees, and associates of bidders on other contemplated work, the same privileges of admission to the Contractor's plant and access to the vessel(s) on a noninterference basis subject to all Contractor rules and regulations governing personnel in its shipyard, including those relative to safety and security. INDEMNIFICATION FOR ACCESS TO VESSELS: Notwithstanding any provision in the "Access to Vessels" clause, or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other prime Contractors with the Government and their subcontractors, and officers, employees, and associates of offeror on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price. INSPECTIONS: Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract. The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation. GROWTH WORK: (a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I will be incorporated. (b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal. (c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC. COMPOSITE LABOR RATE: The composite labor rate offered shall be the sole labor hour rate used to price the prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the prime Contractor's direct labor associated with such changes under this contract. (a) The composite labor hour rate shall represent total compensation for the following: (1) direct labor wages and salaries; (2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits; (3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment; (4) all indirect costs such as overhead and general and administrative expense; (5) any port or association fees, rents, or other levies; (6) profit (fee); and (7) all direct and indirect costs and profit associated with the following support functions: Supervision and Management Material Handling Engineering Quality Assurance Security Planning and Estimating Housekeeping Transportation/Drivers Contract Administration Testing (b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's (c) accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated. (d) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government's best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT: 1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of Government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the Government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed. 2. The items listed in the specification, as Government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all Government furnished property using either a DD Form 1149, entitled, "Requisition and Invoice/Shipping Document" or a DD Form 1348, entitled, "Issue Release/Receipt Document". A copy of the DD 1149 or DD 1348 must be sent within 48 hours of receipt of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator. 3. The Contractor shall complete the report provided herein, entitled, "Government Property Report". This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1(a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator. 4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of Government property to the Coast Guard. This includes Government property taken off the vessel (shafts, propellers, etc.), Government property returned to the vessel (special tools, etc.) or surplus Government property not used during performance of the contract. CONTRACTING OFFICER'S AUTHORITY: No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof. CONTRACTOR PERFORMANCE ASSESSMENT REPORT (CPAR): (a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror's past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award. (b) NOTIFICATION: Upon completion of the contract, the contractor will be notified of the assessment. The contractor will be allowed 30 days to respond to the SLFC's assessment of its performance entered into CPARS. The contractor's response, if any, will be made part of the CPAR system at https://www.cpars.disa.mil. (c) INFORMATION: Information included in the CPAR may include, but is not limited to, the contractor's record of conforming to contract requirements and to standards of good workmanship; the contractor's record of forecasting and controlling costs; the contractor's adherence to contract schedules, including the administrative aspects of performance; the contractor's history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor's record of integrity and business ethics, and generally, the contractor's business-like concern for the interest of the customer. (d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the contractor METHOD OF PAYMENT AND INVOICING INSTRUCTIONS FOR SHIP REPAIR: (A) The U.S. Coast Guard has implemented WINs Remote for the preferred method for contractors to submit all payment requests. As prescribed in FAR Clause 52.232-25, Prompt Payment, all information must be included in an invoice for it to constitute a proper invoice. (B) Each invoice shall contain the following information to ensure proper processing: 1) Contract Number, Delivery Order/Task Order Number, DOC Number 2) Invoice Number and Invoice Date 3) DUNS Number 4) Name of the Contract Specialist and Contracting Officer 5) Invoice Routing Code (IRC): SFLC-2 6) Indicate Small Business Status 7) Indicate if Final Invoice (C) Each Invoice shall be submitted via one of the following methods (In order of preference) 1.) FINCEN Website Invoice Receipt Form: http://www.fincen.uscg.mil/centralinv/central_inv_contr.cfm (FINCEN Web based invoice submission shall be submitted as a single Adobe pdf. formatted file not to exceed 999 pages.) 2.) Fax: 757-523-6900 3.) Mailed To: Commercial Invoices U.S. Coast Guard Finance Center 1430A Kristina Way Chesapeake, VA 23326 (D) Copies of the invoice along with any supporting documentation, shall be sent to the contract specialist and the Contracting Officer's Representative (COR) to the following email addresses below: Contract Specialist (KS/KO): Jack.E.Rodman@uscg.mil Contracting Officer's Representative (COR): Samuel.C.Merritt@uscg.mil (E) In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received: (1) On the later of: (i) For invoices that are mailed or transmitted via facsimile, the date a proper invoice is actually received by the designated billing office and annotates the invoice with date of receipt at the time of receipt. (ii) For invoices electronically transmitted by the contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or (ii) The seventh day after the date on which the property is actually delivered or performance of the services is actually completed; unless- a) The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or b) A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date; (2) On the date placed on the invoice by the contractor, when the agency fails to annotate the invoice with date of receipt of the invoice at the time of receipt (such invoice must be a proper invoice); or (3) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice. (4) Web based submission by the contractor and receipt confirmation does not reflect Government review or acceptance of the invoice. (5) For inquiries and payment status please visit https://fincen.uscg.mil/secure/payment.htm (e) written consent is requested and obtained from the contractor. PROGRESS PAYMENTS A. The Contractor may invoice requesting progress payments without discount, other than any prompt payment discount offered, not more frequently than twice a month. B. The invoice amount should reflect the percentage and dollar amount of completion established by the cutter's appropriate weekly progress report. Payments shall be derived from the accomplished percentage of completion as determined by the Contracting Officer. C. All material and work paid for by progress payments shall thereby become the sole property of the Government, but this provision shall not relieve the Contractor from the obligation to complete the requirements of the contract. D. The contractor shall be paid the remaining amount due upon completion and acceptance of all work under this contract CONTRACT DEFICIENCY REPORT: The Contracting Officer or Contracting Officer's Technical Representative (COTR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COTR. The COTR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor, IBCT Technical Representative, the NESU and Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COTR in writing. (End of FAR 52.212-4 Addendum) 52.212-5 -- Contract Terms and Conditions Required to Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Jan 2014) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). ____ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)). (2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] _X__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402). ___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). ___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). _X__ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2013) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) 52.204-11, American Recovery and Reinvestment Act-Reporting Requirements (Jul 2010) (Pub. L. 111-5). ___ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). ___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). __X_ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (31 U.S.C. 6101 note). __X_ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). ___ (10) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (May 2012) (section 738 of Division C of Public Law 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L. 110-161). ___ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). ___ (12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). ___ (13) [Reserved] _X__ (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). ___ (ii) Alternate I (Nov 2011). ___ (iii) Alternate II (Nov 2011). ___ (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ___ (ii) Alternate I (Oct 1995) of 52.219-7. ___ (iii) Alternate II (Mar 2004) of 52.219-7. ___ (16) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)). ___ (17) (i) 52.219-9, Small Business Subcontracting Plan (Jul 2013) (15 U.S.C. 637 (d)(4)). ___ (ii) Alternate I (Oct 2001) of 52.219-9. ___ (iii) Alternate II (Oct 2001) of 52.219-9. ___ (iv) Alternate III (July 2010) of 52.219-9. ___ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). _X__ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). ___ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ___ (21) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer). ___ (ii) Alternate I (June 2003) of 52.219-23. ___ (22) 52.219-25, Small Disadvantaged Business Participation Program-Disadvantaged Status and Reporting (Jul 2013) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (23) 52.219-26, Small Disadvantaged Business Participation Program-Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323). ___ (24) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f). ___ (25) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). ___ (26) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Jul 2013)(15 U.S.C. 637(m)). ___ (27) 52.219-30, Notice of Set-Aside for Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Jul 2013) (15 U.S.C. 637(m)). _X__ (28) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X__ (29) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2014) (E.O. 13126). _X__ (30) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _X__ (31) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). _X__ (32) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). __X_ (33) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). __X_ (34) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212). __X_ (35) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). ___ (36) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ___ (37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) _X__ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). _X__ (39) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423). ___ (ii) Alternate I (Dec 2007) of 52.223-16. ___ (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011). _X__ (41) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d). ___ (42) (i) 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act (Nov 2012) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, Pub. L. 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). ___ (ii) Alternate I (Mar 2012) of 52.225-3. ___ (iii) Alternate II (Mar 2012) of 52.225-3. ___ (iv) Alternate III (Nov 2012) of 52.225-3. ___ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X__ (44) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ___ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2303 Note). ___ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). ___ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ___ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). ___ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). _X__ (50) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (51) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). ___ (52) 52.232-36, Payment by Third Party (Jul 2013) (31 U.S.C. 3332). ___ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ___ (54) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). ___ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] ___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). ___ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.). ___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.). ___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.). ___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). ___ (7) 52.222-17, Nondisplacement of Qualified Workers (Jan 2013) (E.O. 13495). ___ (8) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). ___ (9) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (ii) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) 52.222-17, Nondisplacement of Qualified Workers (Jan 2013) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212). (vi) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (viii) 52.222-41, Service Contract Act of 1965, (Nov 2007), (41 U.S.C. 351, et seq.) (ix) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). ___ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)). (x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.) (xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.) (xii) 52.222-54, Employment Eligibility Verification (Aug 2013). (xiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xv) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) Alternate I (Feb 2000). As prescribed in 12.301(b)(4)(i), delete paragraph (d) from the basic clause, redesignate paragraph (e) as paragraph (d), and revise the reference to "paragraphs (a), (b), (c), or (d) of this clause" in the redesignated paragraph (d) to read "paragraphs (a), (b), and (c) of this clause". Alternate II (Nov 2013). As prescribed in 12.301(b)(4)(ii), substitute the following paragraphs (d)(1) and (e)(1) for paragraphs (d)(1) and (e)(1) of the basic clause as follows: (d) (1) The Comptroller General of the United States, an appropriate Inspector General appointed under section 3 or 8G of the Inspector General Act of 1978 (5 U.S.C. App.), or an authorized representative of either of the foregoing officials shall have access to and right to- (i) Examine any of the Contractor's or any subcontractors' records that pertain to, and involve transactions relating to, this contract; and (ii) Interview any officer or employee regarding such transactions. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), and (c), of this clause, the Contractor is not required to flow down any FAR clause in a subcontract for commercial items, other than- (i) Paragraph (d) of this clause. This paragraph flows down to all subcontracts, except the authority of the Inspector General under paragraph (d)(1)(ii) does not flow down; and (ii) Those clauses listed in this paragraph (e)(1). Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (A) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)). (B) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (C) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (D) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). (E) 52.222-35, Equal Opportunity for Veterans (Sept 2010) (38 U.S.C. 4212). (F) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). (G) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (H) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). (I) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)). (J) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (Nov 2007) (41 U.S.C. 351, et seq.). (K) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.). (L) 52.222-54, Employment Eligibility Verification (Aug 2013). (M) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (N) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. 3052.212-70 Contract Terms and Conditions Applicable to DHS Acquisition of Commercial Items. CONTRACT TERMS AND CONDITIONS APPLICABLE TO DHS ACQUISITION OF COMMERCIAL ITEMS (SEP 2012) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference: [The Contracting Officer should either check the provisions and clauses that apply or delete the provisions and clauses that do not apply from the list. The Contracting Officer may add the date of the provision or clause if desired for clarity.] (a) Provisions. ____3052.209-72 Organizational Conflicts of Interest. ____3052.216-70 Evaluation of Offers Subject to An Economic Price Adjustment Clause. ____3052.219-72 Evaluation of Prime Contractor Participation in the DHS Mentor Protégé Program. (b) Clauses. ____3052.203-70 Instructions for Contractor Disclosure of Violations. ____3052.204-70 Security Requirements for Unclassified Information Technology Resources. ____3052.204-71 Contractor Employee Access. ____Alternate I __X__3052.205-70 Advertisement, Publicizing Awards, and Releases. ____3052.209-73 Limitation on Future Contracting. ____3052.215-70 Key Personnel or Facilities. ____3052.216-71 Determination of Award Fee. ____3052.216-72 Performance Evaluation Plan. ____3052.216-73 Distribution of Award Fee. __X__3052.217-91 Performance. (USCG) __X__3052.217-92 Inspection and Manner of Doing Work. (USCG) __X__3052.217-93 Subcontracts. (USCG) __X__3052.217-94 Lay Days. (USCG) __X__3052.217-95 Liability and Insurance. (USCG) __X__3052.217-96 Title. (USCG) __X__3052.217-97 Discharge of Liens. (USCG) __X__3052.217-98 Delays. (USCG) __X__3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair. (USCG) __X__3052.217-100 Guarantee. (USCG) ____3052.219-70 Small Business Subcontracting Plan Reporting. ____3052.219-71 DHS Mentor Protégé Program. __X__3052.228-70 Insurance. ____3052.228-90 Notification of Miller Act Payment Bond Protection. (USCG) ____3052.228-91 Loss of or Damage to Leased Aircraft. (USCG) ____3052.228-92 Fair Market Value of Aircraft. (USCG) ____3052.228-93 Risk and Indemnities. (USCG) ____3052.236-70 Special Provisions for Work at Operating Airports. __X__3052.242-72 Contracting Officer's Technical Representative. ____3052.247-70 F.o.B. Origin Information. ____Alternate I ____Alternate II ____3052.247-71 F.o.B. Origin Only. ____3052.247-72 F.o.B. Destination Only. (End of clause)
 

Web Link

FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/USCG/VPLMLCP/HSCG85-14-Q-P45B41/listing.html)
 

Place of Performance

Address: Contractor's Dry-Dock, United States
 

Record

SN03299186-W 20140302/140228234054-c40e35924f0e8ea97c46e69655b910bd (fbodaily.com)
 

Source

FedBizOpps Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's FBO Daily Index Page |