MODIFICATION
J -- USCGC BLACKTIP - Dockside Repairs - Amendment 2
- Notice Date
- 1/4/2012
- Notice Type
- Modification/Amendment
- NAICS
- 336611
— Ship Building and Repairing
- Contracting Office
- Department of Homeland Security, United States Coast Guard (USCG), USCG Surface Forces Logistics Center (SFLC), 2401 Hawkins Point Road, Building 31, Mail Stop 26, Baltimore, Maryland, 21226-5000, United States
- ZIP Code
- 21226-5000
- Solicitation Number
- HSCG80-12-Q-P45B87
- Archive Date
- 1/24/2012
- Point of Contact
- Bernie Caguiat, Phone: 5106375887, Chas Hartley, Phone: 757-628-4657
- E-Mail Address
-
Bernie.C.Caguiat@uscg.mil, chas.f.hartley@uscg.mil
(Bernie.C.Caguiat@uscg.mil, chas.f.hartley@uscg.mil)
- Small Business Set-Aside
- Total Small Business
- Description
- BLACKTIP DS Specification Rev-1 BLACKTIP DS Pricing Sheet - Revision 1 BLACKTIP DS-Amendment 2 This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a separate written solicitation will not be issued. Solicitation number HSCG80-12-Q-P45B87 is issued as a Request for Quotation (RFQ). HSCG80-12-Q-P45B87 and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 05-53. This requirement is being solicited as a Total Small Business Set-aside using Simplified Acquisition Procedures per FAR Subpart 13. The Small Business Size Standard for NAICS 336611 is less than 1,000 employees. This requirement is for a firm-fixed price contract. The anticipated award date is on or about 23 DEC 2011. Work covered by this solicitation shall be completed within thirty-one (31) calendar days from the date the vessel becomes available to the contractor. Work is scheduled to start on 24 JAN 2012 and end on 24 FEB 2012. The Place of Performance will be at the USCGC BLACKTIP home moorings located at 4201 Victoria Avenue, Oxnard, CA 93035. For ship access, please contact MKC Jacob Buckley at (805) 985-7518. The government intends to award from this solicitation to the responsible vendor whose quote conforming to the solicitation provides the best value. DESCRIPTION OF WORK: (a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, power, accessories, facilities and such other things as are necessary, except as otherwise specified, to perform dockside repairs and alterations to the vessel, in accordance with this solicitation and attached specifications. (b) Failure to read the specifications in their entirety will not relieve the quoter from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the quoter's risk. ALL CONTRACTORS ARE RESPONSIBLE FOR VERIFYING THE RECEIPT OF THEIR QUOTES/PROPOSALS. Each quoter shall furnish the information required by the solicitation. Quoter shall provide their DUNS number with their quote. PRICING DATA: Base Contract Line Item Numbers (CLINs) are marked as "D" for Definitive. Optional CLINS are marked "O" for Optional. Insert unit prices in all CLINs listed in the Schedule unless "NSP" is printed in the Unit Price column for any CLIN. "NSP" in the section means "Not Separately Priced." (SEE ATTACHED PRICING SHEET) TRAVEL AND PER DIEM: Work Item O-C, "Travel and Per Diem", is applicable only to Contractors not within the local commuting area (50 miles) of the vessels location. It is anticipated that any Contractors within the 50 mile commuting area will enter "zero" (0) or "N/A" for the unit and extended price for this CLIN, on the Schedule of Supplies or Services. Refer questions to Mr. Bernie Caguiat, Contract Specialist (510) 637-5887. Quotes must arrive no later than 200 P.M. (PST), 6 JAN 2012. Quotations may be e-mailed to Bernie.C.Caguiat@uscg.mil or sent via the US Postal Service or hand delivered to: Commanding Officer, USCG Surface Forces Logistics Center, Attn: Mr. Bernie Caguiat, 1301 Clay Street, Suite 800N, Oakland, CA 94612. E-mailed quotes are subject to the same rules as paper quotes. Inspection and Acceptance is at destination. Vendors should include warrantee terms and conditions and prompt payment discounts with their quotation. PLEASE NOTE: QUOTES THAT DO NOT INCLUDE ALL REQUIRED DOCUMENTS MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED CONTRACT CLAUSES (1) The provision at FAR 52.212-1, Instructions to Offerors - Commercial Items (Jun 2008) (with the exception of paragraph f) and below addendum applies. FAR 52.232-18 Availability of Funds (Apr 1984) Funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer. NOTICE TO OFFERORS: Funds are not presently available for this project. No award will be made under this solicitation until funds are available. The Government reserves the right to cancel this solicitation either before or after the due date for receipt of quotes. FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at: http://www.arnet.gov/index.html. FAR 52.217-5 Evaluation of Options (JUL 1990) FAR 52.211-14 Notice of Priority Rating for National Defense, Emergency Preparedness, and Energy Program Use (Apr 2008), Rated: DO-A3 WELDING CERTIFICATIONS AND QUALIFICATIONS This solicitation may contain welding line items as either Definitive or Optional Items. With his/her quote the Contractor shall provide the necessary welding certifications and qualifications as required by the specification for the applicable work item(s), and SFLC Standard Specification 0740_STD. Subsequent to contract award, the Government will require the Contractor to submit applicable certifications and qualifications to the COTR for any welding to be performed on any proposed change request. FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS (JUN 1988) Orders for U.S. Coast Guard specification reference drawings must be placed within 4 days of the solicitation issue date. To request drawings, contact the Contract Specialist listed herein. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.). Drawing measurements should be verified by the Contractor prior to ordering materials. (2) FAR 52.212-2 EVALUATION-COMMERCIAL ITEMS (JAN 1999) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: The offeror shall identify at least two (2) relevant (construction, overhaul, repair and alteration of ships) federal, state or local government or private contracts performed during the last three (3) years. For each contract, list: a. Contract number and customer point of contact (including two (2) points of contact With telephone numbers) b. Dollar value of the contract (Original and Final) c. Type of service performed and whether Prime or subcontractor d. Required completion date for the contract e. Date the services were actually completed f. Ship Name, Hull Number g. Contract type (FFP, IDIQ, Requirement, Cost Type) h. Percentage of growth in contract price (Additional work divided by award price) If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor. PAST PERFORMANCE: The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a)(2) Past Performance Evaluation. The Contractor's past performance will be evaluated according to the following factors and questions: - Quality of Product or Service Did the customer get what was specified? Did the customer consider the final product high in quality? If warranty issues arose, were they promptly corrected? - Schedule Was the contract completed on time? If not, reason why not (growth work, Contractor delayed, government delayed?) - Business Relations How was the customer service? Was the Contractor committed to customer satisfaction? Would you use this company again (Why/Why not)? - Management of Key Personnel Were subcontracts involved? Comments? In evaluating Contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Assessment Reports and other existing past performance ratings on relevant contracts. General trends in a Contractor's performance will also be considered. PRICE: Offeror's price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness. ****Past Performance is more important than Price**** (End of FAR 52.212-2) (3) The provision at FAR 52.212-3, Offeror Representations and Certifications -- Commercial Items (May 2011) and Alternate 1 (Apr 2011) applies. (4) The provision at FAR 52.212-4 CONTRACT TERMS AND CONDITIONS - COMMERCIAL ITEMS (Jun 2010) and below addendum applies. VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS (a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state's "State Implementation Plan" (SIP) and the type/quantity of the Contractor's regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions. (b) Contractors, therefore, must submit the following to the designated Port Engineer not later than two weeks after contract award: 1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor's facility or offsite work places; 2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor's facility or offsite work places. (c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor's facility or offsite workplaces, then Contractor shall submit to the designated Port Engineer a letter, notarized under oath, that such documents are not required. (d) Contractors will submit the following to the designated Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with MLCA Standard Spec 63000N, Section 5.3.1. REQUIRED INSURANCE The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including: 1. Ship Repairer's Liability - $500,000 per occurrence. 2. Comprehensive General Liability - $500,000 per occurrence. 3. Full insurance coverage in accordance with the United States' Longshoremen's and Harbor Worker's Act. 4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract. The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured. INSPECTIONS Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract. The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation. GROWTH WORK (a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated. (b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal. (c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC. DISCOVERIES AND CHANGES TO CONTRACT: Work requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during an availability: Work Request Process will occur in the following order: 1. Condition Found Report-Generated by the contractor and provided to COTR 2. Condition Report Reply-Generated by the COTR and provided to Contractor 3. Work Request- WR and IGE are generated by the COTR and forwarded to KO 4. COTR provides copy of Work Request to the Contractor 5. Contractor's Proposal- Provided to the KO for the identified tasking on WR 6. Negotiations- If needed, take place to establish pricing 7. Approved Work Request- Forwarded to Contractor and COTR by the KO 8. Modification to Contract- The KS/KO will issue a modification covering all WR's COMPOSITE LABOR RATE: The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract. (a) The composite labor hour rate shall represent total compensation for the following: (1) direct labor wages and salaries; (2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits; (3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment; (4) all indirect costs such as overhead and general and administrative expense; (5) any port or association fees, rents, or other levies; (6) profit (fee); and (7) all direct and indirect costs and profit associated with the following support functions: Supervision and Management Planning and Estimating Material Handling Housekeeping Engineering Transportation/Drivers Quality Assurance Contract Administration Security Testing (b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated. (c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government's best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised. CONTRACTING OFFICER'S AUTHORITY No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof. CONTRACT DEFICIENCY REPORT The Contracting Officer or Contracting Officer's Technical Representative (COTR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COTR. The COTR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COTR in writing. (End of FAR 52.212-4 Addendum) (5) The provision at FAR 52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (May 2011) and below addendum applies. The following FAR Clauses are applicable: 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2010) (Pub. L. 109-282) (31 U.S.C. 6101 note). 52.209-6, Protecting the Government' Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note). (Applies to contracts over $30,000). (Not applicable to subcontracts for the acquisition of commercially available off-the-shelf items). 52.219-6, Notice of Total Small Business Aside (June 2003) (15 U.S.C. 644). 52.219-28, Post Award Small Business Program Rerepresentation (Apr 2009) (15 U.S.C. 632(a)(2)). 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jul 2010) (E.O. 13126). 52.222-21, Prohibition of Segregated Facilities (Feb 1999). 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246). 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793). 52.223-18, Contractor Policy to Ban Text Messaging while Driving (Sep 2010) (E.O. 13513). 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). 52.232-33, Payment by Electronic Funds Transfer-Central Contractor Registration (Oct. 2003) (31 U.S.C. 3332). The provisions of paragraphs a, d, and e are applicable to this contract. (End of Clause)
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/USCG/USCGELC/HSCG80-12-Q-P45B87/listing.html)
- Place of Performance
- Address: HOME MOORAGE, 4201 Victoria Avenue, Oxnard, California, 93035, United States
- Zip Code: 93035
- Zip Code: 93035
- Record
- SN02648282-W 20120106/120104234007-ea9fb2520f887f0342e87735ce24fda5 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |