Loren Data's SAM Daily™

FBO DAILY ISSUE OF JUNE 18, 2009 FBO #2761
SOLICITATION NOTICE

W -- Trailer Rental

Notice Date

6/16/2009
 

Notice Type

Combined Synopsis/Solicitation
 

NAICS

532120 — Truck, Utility Trailer, and RV (Recreational Vehicle) Rental and Leasing
 

Contracting Office

Department of Justice, Federal Prison Industries/UNICOR, Contracting Office/Coleman, 846 N.E. 54th Terrace, P.O. Box 1109, Coleman, Florida, 33521
 

ZIP Code

33521
 

Solicitation Number

FN1293-09
 

Archive Date

7/9/2009
 

Point of Contact

Michael Wilson, Phone: 352-689-4060, Nancy Keeler, Phone: 734-439-1511 ext. 3372
 

E-Mail Address

mxwilson@central.unicor.gov, nancy@central.unicor.gov
(mxwilson@central.unicor.gov, nancy@central.unicor.gov)
 

Small Business Set-Aside

Total Small Business
 

Description

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number is fn1293-09, and this solicitation is issued as a Request for Proposal (RFP). The offer solicitation issue date is JUNE 16, 2009. The offer closing date is JULY 7, 2009 at 2:00pm EST. The solicitation document and incorporated provisions and clauses are those in effect through Federal Prison Acquisition Circular 2005-08. The Standard classification code SIC Code is 7519- Trailer Rental/Lease. UNICOR, Federal Prison Industries, Inc. Intends to enter into a five (5) year firm fixed price requirement type contract for Trailer Rental for FCC Coleman, Florida. Solicitation number is fn1293-09 and this solicitation is issued as a Request for Proposal. UNICOR reserves the right to cancel the contract at any time if an alternate means of storage is obtained. THIS REQUIREMENT IS A TOTAL SMALL BUSINESS SET ASIDE. Offers will be accepted from small business concerns only. The primary and alternate points of contact will be as follows: Michael Wilson, Contract Specialist (primary) 846 NE 54th Terrace Coleman, Fl 33521 352-689-4060 (office) 352-689-7144 (fax) mxwilson@central.unicor.gov Nancy Keeler, Contract Specialist (alternate) Milan FCI E. Arkona Rd. Milan, MI 48160 734-439-1511 x 3372 nancy@central.unicor.gov NAICS Code 532120 Truck, Utility Trailer, and RV (recreational Vehicle) Rental and Leasing. The contractor will provide empty storage trailers to UNICOR as requested. UNICOR will utilize the trailers for storage of raw materials and subassemblies for production. Pricing is requested as follows: Trailer rental/lease per month for an estimated quantity of 70 storage trailers each. UNICOR may require a quantity between 1 and 70 storage trailers each at any given time. Pricing is also requested for trailer delivery (flat fee), and pricing for trailer pickup (flat fee). The trailers are required to be roadworthy and weatherproof. The trailers require tandem axles with an eight (8) foot inside floor dimension. Minimum trailer length is 45 feet. The trailers require (lockable) swing out or roll up doors. Cloth top or refrigeration unit trailers will not be allowed. The contractor will be responsible for the maintenance of the trailers. UNICOR will inspect each trailer as received and the contractor will be responsible for fixing or repairing any problems within 48 hours of notification or remove it from the premises with a replacement. The warehouse staff will fax a completed inspection sheet to the contractor with any problems and/or damages noted. UNICOR will be responsible for any damages incurred while it is in the possession of UNICOR. The contractor will be responsible for delivering and picking up a minimum of five(5)trailers within a five (5) day period. The UNICOR Warehouse Staff will be responsible for calling the contractor for pickups, deliveries and/or repairs. Due to the trailers being stored at the Federal Correctional Institution, UNICOR reserves the right to store the trailers off site if the situation arises. The minimum delivery order quantity is one (1) each and the maximum delivery order quantity is seventy (70) each. Initial delivery of trailers must be within fifteen (15) days of contract award. CONTRACT ADMINISTRATION DATA - JAR 2852.201-70 CONTRACTING OFFICER'S TECHNICAL REPRESENTATIVE (COTR) (JAN 1985) Supplement: LCL APPR Edward Judy, UNICOR Maintenance Foreman The COTR is responsible, as applicable, for: receiving all deliverable's, inspecting and accepting the supplies or services provided hereunder in accordance with the terms and conditions of this contract; providing direction to The contractor which clarifies the contract effort, fills in details or otherwise serves to accomplish the contractual Scope of Work; evaluating performance; and certifying all invoices/vouchers for acceptance of the supplies or services furnished for payments. The COTR does not have the authority to alter the contractor's obligations under the contract, and/or modify any of the expressed terms, conditions, specifications, or cost of the agreement. If as a result of technical discussions, it is desirable to alter/change contractual obligations or the Scope of Work, the Contracting Officer shall issue such changes in writing and signed. ADMINISTERED BY: This contract will be administered by: UNICOR, Federal Correctional Complex (UNICOR), 846 NE 54th Terrace, Coleman, Fl 33521. Written communications shall make reference to the contract number and shall be mailed to the above address. Offers shall indicate below the complete mailing address (including the nine digit ZIP code) to which remittance should be mailed if such address is other that shown in block 15A, Page 1 (Standard form 1449), they shall enter it below: Payee Name (Contractor):________________________ Check Remittance Address: Any Questions or problems regarding payment should be directed to the Business Manager at the following location: UNICOR FPI Central Acct Payable P.O. Box 4000 Butner, NC 27509-4000 Funds will be obligated by each delivery order and not by the contract itself. OMB 1103-0018 The following FAR clauses and provisions apply to this acquisition: 52.204-6 Contractor Identification Number Data Universal Numbering System (DUNS); 52.212-1 Instructions to Offers - Commercial; 52.212-2 Evaluation - Commercial Items, significant evaluation factors are past performance, ability to meet specification and price. Past performance and ability to meet specification are more important than price. 52.212-3 Offers Representations and Certifications - Commercial Items (MAR 05) IAW FAR 4.1201(a). 52.233 1 Disputes (July 2002) (DEVIATION) (a) This contract is not subject to the Contract Disputes Act of 1978 (41 U.S.C.601 613). (b) All disputes arising under or relating to this contract shall be resolved under this clause. (c) AClaim,@ as used in this clause, means a written demand or written assertion by one of the contracting parties seeking, as a matter of right, the payment of money in a sum certain, the adjustment or interpretation of contract terms, or other relief arising under or relating to this contract. However, a written demand or written assertion by the Contractor seeking the payment of money exceeding $100,000 is not a claim until certified. A voucher, invoice, or other routine request for payment that is not in dispute when submitted is not a claim. The submission may be converted to a claim by complying with the submission and certification requirements of this clause, if it is disputed either as a liability or amount or is not acted upon in a reasonable time. (d)(1) A claim by the Contractor shall be made in writing and, unless otherwise stated in this contract, submitted within 6 years after accrual of the claim to the Contracting Officer for a written decision. A claim by the Government against the Contractor shall be subject to a written decision by the Contracting Officer. (2)(i) The Contractor shall provide the certification specified in paragraph (d)(2)(iii) of this clause when submitting any claim exceeding $100,000. (ii) The certification requirement does not apply to issues in controversy that have not been submitted as all or part of a claim. (iii) The certification shall state as follows: AI certify that the claim is made in good faith; that the supporting data are accurate and complete to the best of my knowledge and belief; that the amount requested accurately reflects the contract adjustment for which the Contractor believes the Government is liable; and that I am duly authorized to certify the claim on behalf of the Contractor.@ (3) The certification may be executed by any person duly authorized to bind the Contractor with respect to the claim. (e) For the Contractor claims of $100,000 or less, the Contracting Officer must, if requested in writing by the contractor, render a decision within 60 days of the request. For contractor certified claims over $100,000, the Contracting Officer must, within 60 days, decide the claim or notify the Contractor of the date by which the decision will be made. (f) The Contracting Officer=s decision shall be final unless the Contractor appeals to the Chief, Procurement Branch, UNICOR, Federal Prison Industries within 90 days of the date of the Contractor's receipt of the adverse decision. The decision of the Chief, Procurement Branch on a Contractor's appeal will be final. (g) Within 10 days of the Contractor's receipt of an adverse Contracting Officer's decision on a claim, the Contractor may request, and Federal Prison Industries will participate in, non binding alternative dispute resolution (ADR) by means mutually acceptable to the parties. Any ADR shall be completed within 60 days of the Contractor's request, unless the parties agree to a longer period. A Contractor's request for, and participation in, ADR will not toll the 90 day time limit within which to appeal an adverse Contracting Officer's decision to the Chief, Procurement Branch. (h) The Government shall pay interest on the amount found due and unpaid from (1) the date that the Contracting Officer receives the claim (certified, if required); or (2) the date that payment otherwise would be due, if that date is later, until the date of payment. With regard to claims having a defective certifications, as defined in FAR 33.201, interest shall be paid from the date that the Contracting Officer initially receives the claim. Simple interest on claims shall be paid at the rate, fixed by the Secretary of the Treasury, which is applicable to the period during which the Contracting Officer receives the claim and then at the rate applicable for each 6 month period as fixed by the Treasury Secretary during the pendency of the claim. (i) The Contractor shall proceed diligently with performance of this contract, pending final resolution of any request for relief, claim, appeal, or action arising under the contract, and comply with any decision of the Contracting Officer. (End of clause) 52.212-5, Contract Terms and Conditions Required to Implement Statues or Executive Orders - Commercial Items, (APR 2005) which includes: 52.203-6, Restrictions on Subcontractor Sales to the Government, with Alternate I; 52.232-33, Payments of Electronic Funds Transfer - Central Contractor Registration; 52.233-4 Applicable Law for Breach of contract claim 52.216-18, Ordering, orders may be issued under the resulting contract from date of award through five (5) years thereafter. 52.202-1 Definitions 52.203-5 Covenant Against Contingent Fees 52.203-6 Restriction on Subcontractor Sales to the Government 52.203-7 Anti-Kickback Procedures 52.208-4, Vehicle Lease Payments (4/84) 52.208-5, Condition of Leased Vehicles (4/84) 52.211-5 Material Requirements 52.211-11 Liquidated Damages - Supplies, Services, or Research and Development. (SEP 2000) 52.211-16, Variation in Quantity =/-% 0 52.216-21, Requirements (OCT 1995) 52.217-6 Option for Increased Quantity 52.219-6 Notice of Total Small Business Set-Aside 52.222-21 Prohibition of Segregated Facilities (Feb 1999) 52.222-3 Convict Labor 52.222-41 Service Contract Act of 1965, As Amended (41 U.S.C. 351, et seq.). 52.223-14 Certification of Toxic Chemical Release Reporting 52.225-13 Restrictions on Certain Foreign Purchases 52.228-8, Liability and Insurance - Leased Motor Vehicles (5/99) 52.232-1 Payments ( APR 1984) 52.232-18, Availability of Funds; 52.232-25 Prompt Payment 52.232-34 Payment by Electronics Fund Transfer - Other than Central Contractor Registration 52.233-1 Disputes 52.233-3, Protest After Award 52.233-4 Applicable Law for Breach of Contract 52.244-6 Subcontracts for Commercial Items 52.244-6 Subcontracts for Commercial Items 52.246-2 Inspection of Supplies - Fixed Price 52.246-1 Contractor Inspection Requirements. APR 1984 52.246-15 Certificate of Performance 52.246-16 Responsibility for Supplies. APR 1984 52.247-34 F.O.B. Destination 52.249-2 Termination for Convenience 52.249-8 Default (Fixed-Price Supply and Services) 52.247-34, F.O.B. Destination, delivery shall be FOB DESTINATION TO UNICOR, Federal Correctional Complex, 846 NE 54th Terrace, Coleman, Fl 33521. Delivery hours are Monday Thru Friday 7:00am to 3:00pm EST excluding Federal holidays. Any shipping questions, call Leroy Simmons at 352-689-4293. 52.215-5 Facsimile Proposals Facsimile proposal, as used in this provision, means a proposal, revision or modification of a proposal, or withdrawal of a proposal that is transmitted to and received by the Government via facsimile machine. (b) Offerors may submit facsimile proposals as responses to this solicitation. Facsimile proposals are subject to the same rules as paper proposals. (c) The telephone number of receiving facsimile equipment is: [insert telephone number]. (d) If any portion of a facsimile proposal received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document -- (1) The Contracting Officer immediately shall notify the offeror and permit the offeror to resubmit the proposal; (2) The method and time for resubmission shall be prescribed by the Contracting Officer after consultation with the offeror; and (3) The resubmission shall be considered as if it were received at the date and time of the original unreadable submission for the purpose of determining timeliness, provided the offeror complies with the time and format requirements for resubmission prescribed by the Contracting Officer. (e) The Government reserves the right to make award solely on the facsimile proposal. However, if requested to do so by the Contracting Officer, the apparently successful offeror promptly shall submit the complete original signed proposal. 52.211-11 Liquidated Damages - Supplies, Services, or Research and Development. (SEP 2000) (a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of 2% per calendar day of delay. (b) If the Government terminates this contract in whole or in part under the Default - Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default - Fixed-Price Supply and Service clause in this contract. NOTE: The government reserves the right to charge actual damages against orders for non conformance to the contract. Damages will be documented and provided to vendor prior to deductions being taken. 52.223-13 Certification of Toxic Chemical Release Reporting (a) Executive Order 13148, of April 21, 2000, Greening the Government through Leadership in Environmental Management, requires submission of this certification as a prerequisite for contract award. (b) By signing this offer, the offeror certifies that- (1) As the owner or operator of facilities that will be used in the performance of this contract that are subject to the filing and reporting requirements described in section 313 of the Emergency Planning and Community Right-to-Know Act of 1986 (EPCRA) (42 U.S.C. 11023) and section 6607 of the Pollution Prevention Act of 1990 (PPA) (42 U.S.C. 13106), the offeror will file and continue to file for such facilities for the life of the contract the Toxic Chemical Release Inventory Form (Form R) as described in sections 313(a) and (g) of EPCRA and section 6607 of PPA; or (2) None of its owned or operated facilities to be used in the performance of this contract is subject to the Form R filing and reporting requirements because each such facility is exempt for at least one of the following reasons: [Check each block that is applicable.] [ ] (i) The facility does not manufacture, process, or otherwise use any toxic chemicals listed in 40 CFR 372.65; [ ] (ii) The facility does not have 10 or more full-time employees as specified in section 313(b)(1)(A) of EPCRA, 42 U.S.C. 11023(b)(1)(A); [ ] (iii) The facility does not meet the reporting thresholds of toxic chemicals established under section 313(f) of EPCRA, 42 U.S.C. 11023(f) (including the alternate thresholds at 40 CFR 372.27, provided an appropriate certification form has been filed with EPA); [ ] (iv) The facility does not fall within the following Standard Industrial Classification (SIC) codes or their corresponding North American Industry Classification System sectors: (A) Major group code 10 (except 1011, 1081, and 1094. (B) Major group code 12 (except 1241). (C) Major group codes 20 through 39. (D) Industry code 4911, 4931, or 4939 (limited to facilities that combust coal and/or oil for the purpose of generating power for distribution in commerce). (E) Industry code 4953 (limited to facilities regulated under the Resource Conservation and Recovery Act, Subtitle C (42 U.S.C. 6921, et seq.), or 5169, or 5171, or 7389 (limited to facilities primarily engaged in solvent recovery services on a contract or fee basis); or [ ] (v) The facility is not located in the United States or its outlying areas.. 52.225-18 Place of Manufacture a) Definitions. As used in this clause- " Manufactured end product" means any end product in Federal Supply Classes (FSC) 1000-9999, except- (1) FSC 5510, Lumber and Related Basic Wood Materials; (2) Federal Supply Group (FSG) 87, Agricultural Supplies; (3) FSG 88, Live Animals; (4) FSG 89, Food and Related Consumables; (5) FSC 9410, Crude Grades of Plant Materials; (6) FSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) FSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) FSC 9610, Ores; (9) FSC 9620, Minerals, Natural and Synthetic; and (10) FSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. (b) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) o In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) o Outside the United States. 52.233-2 Service of Protest SERVICE OF PROTEST (SEPT 2006) (a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from _Nancy Keeler__ Milan FCI E. Arkona Rd. Milan, MI 48160 734-439-1511 x 3372 nancy@central.unicor.gov [Contracting Officer designate the official or location where a protest may be served on the Contracting Officer.] (b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO. Prospective contractors shall complete electronic annual representations and certifications at http://orca.bpn.gov in conjunction with required registration in the Central Contractor Registration (CCR) database (see FAR 4.1102) (b) Prospective contractors shall update the representations and certifications submitted to ORCA as necessary, but at least annually, to ensure they are kept current, accurate, and complete. SECTION K - REPRESENTATIONS AND CERTIFICATIONS Beginning January 1, 2005, the Federal Acquisition Regulation (FAR) will require the use of the Online Representations and Certifications Application (ORCA) in Federal solicitations as a part of the proposal submission process. ORCA is a web-based system that centralizes and standardizes the collection, storage and viewing of many of the FAR required representations and certifications previously found in solicitations. With ORCA, you now have the ability to enter and maintain your representation and certification information, at your convenience via the Internet at http://orca.bpn.gov. In addition, rather than receiving and reviewing paper submissions, government contracting officials can access ORCA and review your information online as a part of the proposal evaluation process. You will no longer have to submit representations and certifications completed in ORCA with each offer. Instead, a solicitation will contain a single provision that will allow you to either certify that all of your representations and certifications in ORCA are current, complete and accurate as of the date of your signature, or list any changes. Although architect-engineer firms can voluntarily submit the Standard Form (SF) 330 Part II through ORCA, they still must submit this form to each agency for which it wants to be considered for projects that are not publicly announced. To prepare for this requirement and to register in ORCA, you will need to have two items: an active Central Contractor Registration (CCR) record and a Marketing Partner Identification Number (MPIN) identified in that CCR record. Your DUNS number and MPIN act as your companies ID and password into ORCA. (Visit www.ccr.gov for more information on creating and entering your MPIN). The basic information provided in your CCR record is used to pre-populate a number of fields in ORCA. Vendors are reminded to protect their MPIN from unauthorized use. Once in ORCA you will be asked to review pertinent information pre-populated from CCR, provide a point of contact, and answer a questionnaire that contains up to 26 questions. The questionnaire is to help you gather information you need for the clauses. The questionnaire is not the official version. Be sure to read the provisions carefully. The answers you provide are then automatically entered into the actual FAR provisions. You are required to review your information, as inserted, in context of the full-text provisions for accuracy; acknowledge three additional read only provisions; and click a time/date stamp before final submission. You will need to review and/or update your ORCA record when necessary, but at least annually in order to maintain its active status. Detailed information regarding ORCA, how to submit your record, and whom to call for assistance can be found on ORCAs homepage at http://orca.bpn.gov under Help. Teresa Sorrenti, IAE Program Manager Integrated Acquisition Environment, @011 Crystal Drive, Crystal Park 1, Suite 911, Arlington, VA 22202. Tel. 703-872-8600, Fax 703-872-8598, email integrated,acquisition@gsa.gov, http:egov.gsa.gov PROPOSAL SUBMISSION REQUIREMENTS: Offerors are required to submit the following information to be considered for award. Each proposal package shall consist of the following completed and signed documents: SF1449, all amendments issued, three (3) Business Management Questionnaires with recent and relevant contracts for the same or similar items IAW FAR 52.212-1 A Completed ACH form must be submitted with each solicitation package prior to contract award. Implementation of the Central Contractor Registration (CCR) was mandated effective October 1, 2003. All contractors MUST register in the CCR prior to award and maintain registration on CCR through final payment. For additional information and to register, go to www.ccr.gov Offerors shall submit signed and dated offers to UNICOR, Federal Correctional Complex, 846 NE 54th Terrace, Coleman, Fl 33521 ATTN: Michael Wilson. This information shall be displayed on the outside of the envelope with the solicitation number and offer closing date. Offerors may fax proposals to 352-689-7144 before the offer closing date and time. Offers received after the exact time and date specified will not be considered. Offers who submit fax proposals must provide an original within (2) two days of the closing date. The Government intends to award a contract resulting from this solicitation to the responsible offeror whose offer represents the best value to the government. The following factors shall be used to evaluate proposals: Past Performance, ability to meet specification and price. A written notice of award or acceptance of an offer will be mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract. The solicitation will be available on Fedbizops at www.fbo.gov on or about jUNE 12, 2009. No copies of the solicitation will be mailed. All responsible offerors may submit a proposal which will be considered.
 

Web Link

FBO.gov Permalink
(https://www.fbo.gov/spg/DOJ/FPI-UNICOR/COL/FN1293-09/listing.html)
 

Place of Performance

Address: Federal Prison Industries (UNICOR), 846 NE 54TH Terrace, Coleman, Fl 33521, Coleman, Florida, 33521, United States

Zip Code: 33521
 

Record

SN01847111-W 20090618/090617000820-9affe2a88a18d12a03d64e058ac4fdab (fbodaily.com)
 

Source

FedBizOpps Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's FBO Daily Index Page |