MOD | Y | Grease trap system replacement for buildingQuestions answered: No time extension given.

FBO DAILY ISSUE OF DECEMBER 21, 2007 FBO #2216
MODIFICATION

Y -- Grease trap system replacement for buildingQuestions answered: No time extension given.

Notice Date: 12/19/2007
Notice Type: Modification
NAICS: 237110 — Water and Sewer Line and Related Structures Construction
Contracting Office: Department of Veterans Affairs;VAMC Northampton;Acquisitions-001A;421 North Main Street;Leeds MA 01053-9764
ZIP Code: 01053-9764
Solicitation Number: VA-241-08-RQ-0046
Response Due: 12/28/2007
Archive Date: 2/26/2008
Point of Contact: Jane LaBorde Contract Specialist 413-584-4040 ext. 2404
E-Mail Address: Email your questions to VA CONTRACTING OFFICER
(JANE.LABORDE@VA.GOV)
Small Business Set-Aside: Service-Disabled Veteran-Owned
Description: 1. The existing concrete grease trap has a 14 foot interior depth and consists of 12" thick cast concrete walls and floor. 2. The existing retaining wall adjacent to the existing grease trap is not part of the existing grease trap and the retaining wall does not need to be removed. 3. Notes 9, 10 and 16 indicate that all utility locations are approximate and must be field verified by the contractor. NO TIME EXTENSION GIVEN. RESPONSE DUE: DEC 28, 2007 VAMC NORTHAMPTON GREASE TRAP SOLICITATION VA-241-08-RQ-0046 AMENDMENT 3
Place of Performance: Address: VAMC NORTHAMPTON BLDG 5;421 N MAIN STREET;LEEDS, MA; Zip Code: 01053; Country: USA
Record: SN01472997-W 20071221/071219223516 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |