SOLICITATION NOTICE
H -- H-Laboratory Testing Services for Construction Project
- Notice Date
- 7/29/2003
- Notice Type
- Solicitation Notice
- Contracting Office
- Attn: Department of Veterans Affairs Tennessee Valley Health Care System, Alvin C. York Campus, Chief, Acquisition Section (90C), 3400 Lebanon Road, Murfreesboro, Tennessee 37129
- ZIP Code
- 37129
- Solicitation Number
- 249-03-30
- Response Due
- 8/12/2003
- Archive Date
- 9/11/2003
- Point of Contact
- Point of Contact - Jerry Shepherd, Contracting Officer, (615) 867-5412, Contracting Officer - Jerry Shepherd, Contracting Officer, (615) 867-5412
- E-Mail Address
-
Email your questions to Jerry Shepherd
(jerry.shepherd@med.va.gov)
- Description
- Contractor shall provide full commerical testing services and facilities or laboratories for certain testing during construction of project 614-011 Seismic/Mordenization, Phase II in accordance with Section 01410. Place of perrormance for this contract shall the the VA Medical Center, Memphis, TN. Contractor shall have the following minimum qualifications: A) Principals of the testing laboratory must be registered professional engineers with not less than five years experience in the types of testing under this contract. B) Each person in charge of laboratory testing, field testing and inspection must have not less that one year full time experience in duties performed under this contract. C) Although we require the principals of the firm to be registered, personnel who are not registered may perform most of the work. D) The contract will be for a lump sum based on the estimated number of tests and days of field inspection, however, include unit prices are to be included. E) Contract performance period shall coincide with the estimated performance period of the construction contract period of 914 calendar days. the performance period shall remain in force for the full duration of the construction contract including all delays and/or time extensions. Cost range shall be $100,000 to $250,000. NAICS 541380, size standard is $6.0 million. This procurement is a 100% small business set-aside. Award is subject to FY03 funds being available.
- Web Link
-
RFQ 249-03-30
(http://www.bos.oamm.va.gov/solicitation?number=249-03-30)
- Record
- SN00385807-W 20030731/030729213539 (fbodaily.com)
- Source
-
FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |